Power Failure Power Failure means the failure of power or other utility service if the failure takes place off the "residence premises". But if the failure results in a loss, from a Peril Insured Against on the "residence premises", we will pay for the loss caused by that peril.
Lenders’ Failure to Perform All Advances (other than Swing Loans and Agent Advances) shall be made by the Lenders contemporaneously and in accordance with their Pro Rata Shares. It is understood that (i) no Lender shall be responsible for any failure by any other Lender to perform its obligation to make any Advance (or other extension of credit) hereunder, nor shall any Commitment of any Lender be increased or decreased as a result of any failure by any other Lender to perform its obligations hereunder, and (ii) no failure by any Lender to perform its obligations hereunder shall excuse any other Lender from its obligations hereunder.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
H5 Disruption The Contractor shall take reasonable care to ensure that in the performance of its obligations under the Contract it does not disrupt the operations of the Authority, its employees or any other contractor employed by the Authority.
No Failure to Cure Default The Seller has not received a written notice of default of any senior mortgage loan related to the Mortgaged Property which has not been cured;
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Epidemic Failure “Epidemic Failure” for any particular Product shall mean a failure resulting from defects in material, workmanship, and manufacturing process, including but not limited to the use of Components with known defects. The Epidemic Failure clause shall be invoked [***]. The failure rate may be calculated [***], as determined by BUYER. Epidemic failures do not supersede the requirements of any expressed or implied warranty defined herein. In the case of an epidemic failure, SUPPLIER’s obligation is to propose an action plan to fix the failure of any affected Product within seventy-two (72) hours of discovery. SUPPLIER shall implement this action plan upon BUYER’s acceptance thereof. If the action plan is not acceptable to BUYER, BUYER can require SUPPLIER to repair or replace, at BUYER’s option, the affected Product. In addition to bearing the costs associated therewith, if requested by BUYER, SUPPLIER shall support and provide at SUPPLIER’s expense a sufficient number of units of the Product to permit the field exchange or “hot swap” of Products at customer sites. The parties agree to make all reasonable efforts to complete the repair or replacement of all affected Products within eight (8) Business Days after written notice of epidemic failure by BUYER to SUPPLIER. SUPPLIER also agrees that BUYER will be supported with accelerated shipments of replacement Product to cover BUYER’s supply requirements. If an Epidemic Failure is caused by (i) a design, including a BUYER-provided test process, as required by the Specifications or (ii) a failure by a Component required by the Specifications, (iii) misuse or damage during transit or damage by a third party at no fault of SUPPLIER, SUPPLIER shall perform the obligations in this Section 10.5 and BUYER shall pay to SUPPLIER the fees mutually agreed upon by the parties in writing. If an Epidemic Failure is caused by any other reason other than as set forth in the immediately preceding sentence, SUPPLIER shall perform the obligations set forth in this Section free of charge. Confidential treatment is being requested for portions of this document. This copy of the document filed as an exhibit omits the confidential information subject to the confidentiality request. Omissions are designated by the symbol [***]. A complete version of this document has been filed separately with the Securities and Exchange Commission.
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
