BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply:
BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Certification Regarding Entire TIPS Agreement for Part 1 and Part 2 Contracts 5 This is a two part solicitation. Part 1 is solicited for TIPS sales that are not considered a "public work" construction project. Part 1 permits the sale of goods and non-construction/non-"public work" services such as maintenance and minor repairs. Part 2 Job Order Contract (JOC) is solicited for projects considered by your TIPS Member Customers to be a "public work" construction project. The determination of whether or not a TIPS sale amounts to a "public work" construction project requiring a Part 2 JOC contract is made by the TIPS Member Customer at the time of each TIPS sale. Thus, Vendors are encouraged to respond to both Parts 1 and 2 in case your TIPS Member Customers require that a sale be made under one Part or the other. However, responding to both Parts is not required. If Vendor responds and is awarded to both Parts, Vendor will have one contract for Part 1 and a separate contract for Part 2.
Subcontracting for the Provision of Services (a) The parties acknowledge that, subject to the provisions of LHSIA, the HSP may subcontract the provision of some or all of the Services. For the purposes of this Agreement, actions taken or not taken by the subcontractor, and Services provided by the subcontractor, will be deemed actions taken or not taken by the HSP, and Services provided by the HSP.
RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.
Contractors Submission Respecting the Agreement The Contractor shall, as part of the Contractor's submission respecting this Contract, complete the attached Schedule B, Identification of Principles; Schedule C, Schedule of Tendered Unit Prices; Schedule D, Schedule of Equipment to be used on the work; and Schedule E, Schedule of Sub-Contractors. The Contract including all appended schedules shall be completed in complete conformity with the instructions to bidders contained in the document entitled "General Provisions and Contract Specification for Highway Construction". In presenting the Contractor’s submission for consideration by the Minister, the Contractor understands that until, and unless, the Contract is endorsed by the Minister, no Contract between the parties shall exist and the Minister shall not be bound to endorse any Contract.
Liability for Failure to Stop Payment of Preauthorized Transfer If you order us to stop one of these payments 3 business days or more before the transfer is scheduled, and we do not do so, we will be liable for your losses or damages.
Liability for Failure to Stop Payment of Preauthorized Transfers If you order us to stop payment of a preauthorized transfer three (3) business days or more before the transfer is scheduled and we do not do so, we will be liable for your losses or damages.
Environmental constraints and management Describe or cross refer to environmental constraints applicable to the Contractor’s plan and his activities on the Affected Property and how they should be managed. Include here or cross refer to an Annexure to the Service Information. The Contractor shall comply with the environmental criteria and constraints stated in Annexure
