Owner's Decision Sample Clauses

Owner's Decision. 34.3.1 If any dispute or difference of any kind whatsoever shall arise between the Owner and the Contractor, arising out of this Contract whether during the performance of the obligations under this Contract or after its completion or whether before or after the termination, Abandonment or breach of this Contract, such dispute or difference cannot be amicably settled by the Parties in accordance with Clause 34.1, it shall, in the first place, be referred to and settled by the Managing Director of the Owner, who, within a period of 30 (thirty) days after being requested to do so, shall give written notice of its decision to the Contractor.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Owner's Decision. 39.2.1 If any dispute or difference of any kind whatsoever shall arise between the Owner and the Contractor, arising out of this Contract whether during the performance of the Services or after its completion or whether before or after the termination, Abandonment or breach of this Contract, such dispute or difference cannot be amicably settled by the Parties, it shall, in the first place, be referred to and settled by the Managing Director of the Owner, who, within a period of 30 (thirty) days after being requested to do so, shall give written notice of its decision to the Contractor. 39.2.2 Save as hereinafter provided, such decision in respect of every matter so referred shall be final and binding upon the Parties until the completion of the entire Services under this Contract and shall forthwith be given effect to by the Parties who shall comply with all such decisions, with all due diligence, whether it requires arbitration, as hereinafter provided or not. 39.2.3 If after the Owner has given written notice of its decision to the Contractor and no notice to arbitration has been communicated to it by the Contractor within 30 (thirty) days from the receipt of such notice, the said decision shall become final and binding on the Parties. 39.2.4 The Owner's decision (or the failure of the Owner to give decision within the time specified in Clause 39.2.1) and issuance of a written notice for arbitration pursuant to Clause 39.2.3 shall be a condition precedent to the right to request arbitration. It is the intent of this Contract that there shall be no delay in the execution of the Services and the decision of the Owner, as rendered, shall be promptly observed. 39.2.5 In the event of the Owner failing to notify its decision, as aforesaid, within 30 (thirty) days after being requested, or in the event of a Party being dissatisfied Contract for Horticulture Maintenance and Landscaping Page 38 Plant: 2X363.3 MW GAS BASED COMBINED CYCLE POWER PLANT
Sample 1See All (4)
Owner's Decision. 46.3.1 If any dispute or difference of any kind whatsoever shall arise between the Owner and the O&M Operator, arising out of this Contract whether during the performance of its obligations or after its completion or whether before or after the termination, Abandonment or breach of this Contract, such dispute or difference cannot be amicably settled by the Parties in accordance with Clause 46.1, it shall, in the first place, be referred to and settled by the Managing Director of the Owner, who, within period of 30 (thirty) days after being requested to do so, shall give written notice of its decision to the O&M Operator.
Sample 1
Owner's Decision. 10.1 In respect of all matters which are left to the decision of the Owner including the granting or withholding of the certificates, the Owner shall, if required to do so by the Contractor, give in writing a decision thereon.
Sample 1
Owner's Decision. Problem We obtain the owner’s expected profit for two options and W = k + 1 L = + 1 Time each needs to consider two cases –i.e. (i) y ≤ γ y > γ . and (ii)
Sample 1
Owner's Decision. 39.2.1 If any dispute or difference of any kind whatsoever shall arise between the Owner and the Contractor, arising out of this Contract whether during the performance of the Services or after its completion or whether before or after the termination, Abandonment or breach of this Contract, such dispute or difference cannot be amicably settled by the Parties, it shall, in the first place, be referred to and settled by the Managing Director of the Owner, who, within a period of 30 (thirty) days after being requested to do so, shall give written notice of its decision to the Contractor. 39.2.2 Save as hereinafter provided, such decision in respect of every matter so referred shall be final and binding upon the Parties until the completion of the entire Services under this Contract and shall forthwith be given effect to by the Parties who shall comply with all such decisions, with all due diligence, whether it requires arbitration, as hereinafter provided or not.
Sample 1
Owner's Decision. OWNER will render a formal decision in writing within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. OWNER’s written decision on such Claim, dispute, or other matter will be final and binding upon ENGINEER unless:
Sample 1
AutoNDA by SimpleDocs
Owner's Decision. The Owner shall give due consideration to all sketches, drawings, specifications, tenders, proposals, contracts and other documents laid before the Owner by the Consultant, and wherever prompt action is necessary, the Owner shall inform the Consultant of its decisions in such reasonable time as not to delay the Services.
Sample 1

Related to Owner's Decision

  • Final Decision Concessionaire covenants that the decision of the Commissioner of Department, relative to the performance of the terms and conditions of this Agreement, shall be final and conclusive.

  • Arbitrator’s Decision 27.3.3.1 The arbitrator's decision and award shall be in writing and shall state concisely the reasons for the award, including the arbitrator's findings of fact and conclusions of law.

  • Final Decisions The Contracting Officer will issue a final decision as required by 33.211 if—

  • Arbitration Decisions Unless otherwise agreed by the Parties, the arbitrator(s) shall render a decision within ninety (90) Calendar Days of appointment and shall notify the Parties in writing of such decision and the reasons therefor. The arbitrator(s) shall be authorized only to interpret and apply the provisions of this LGIA and shall have no power to modify or change any provision of this Agreement in any manner. The decision of the arbitrator(s) shall be final and binding upon the Parties, and judgment on the award may be entered in any court having jurisdiction. The decision of the arbitrator(s) may be appealed solely on the grounds that the conduct of the arbitrator(s), or the decision itself, violated the standards set forth in the Federal Arbitration Act or the Administrative Dispute Resolution Act. The final decision of the arbitrator(s) must also be filed with FERC if it affects jurisdictional rates, terms and conditions of service, Interconnection Facilities, or Network Upgrades.

  • Impartial Decisions The Design Professional is the interpreter of the conditions of the Construction Contract and the judge of its performance, in the first instance. The Design Professional shall side neither with the Owner nor with the Contractor, but shall use its powers to enforce performance by both.

  • Arbitration Decision The arbitrator’s decision will be final and binding. The arbitrator shall issue a written arbitration decision revealing the essential findings and conclusions upon which the decision and/or award is based. A party’s right to appeal the decision is limited to grounds provided under applicable federal or state law.

  • The Decision If mediation fails, or is not appropriate, and if the decision can be rendered after a short deliberation, the Arbitrator will do so. By meeting first with counsel to explain the framework of the Arbitrator’s decision, the parties are provided with an opportunity to influence the exact terms of resolution. Within the framework of settlement as outlined by the Arbitrator, the parties can work out exact terms which best suit the specifics of the case. Such an opportunity should not be wasted by continuing to argue the merits of the case.

  • Advice of Minister’s decision (2) The Minister shall within two months after receipt of proposals pursuant to subclause (1) of Clause 7 or where the proposals are to be assessed under section 40(1)(b) of the EP Act then within two months after service on him of an authority under section 45(7) of the EP Act give notice to the Company of his decision in respect to the proposals. Consultation with Minister

  • Hearing Decision The decision of the Board shall be in writing and shall contain findings of fact and the personnel action approved, if any. The findings may reiterate the language of the pleadings or simply refer to them. The decision of the Board shall be certified to the Superintendent or designee who recommended the personnel action, and he/she shall enforce and follow this decision. A copy of the decision shall be delivered to the appellant or his/her designated representative personally or by registered mail. The decision of the Board shall be final.

  • Automated decisions For purposes hereof “automated decision” shall mean a decision by the data exporter or the data importer which produces legal effects concerning a data subject or significantly affects a data subject and which is based solely on automated processing of personal data intended to evaluate certain personal aspects relating to him, such as his performance at work, creditworthiness, reliability, conduct, etc. The data importer shall not make any automated decisions concerning data subjects, except when:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!