Owner’s Right To Suspend For Convenience Sample Clauses

Owner’s Right To Suspend For Convenience. Owner may at any time, with or without cause, suspend, delay, reduce or interrupt performance of all or any portion of the Work for such period or periods as Owner elects by giving Contractor written notice specifying which portion of the Work is to be suspended and the effective date of such suspension. Such suspension, delay or interruption shall continue until Owner terminates such suspension, delay or interruption by written notice to Contractor. No such suspension, delay, interruption or reduction by Owner shall constitute a breach or default by Owner under the Contract Documents. Contractor shall continue to diligently perform any remaining Work that is not suspended, delayed, reduced or interrupted and shall take all actions necessary to maintain and safeguard all materials, equipment, supplies and Work in progress affected by the suspension, delay, reduction or interruption.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Owner’s Right To Suspend For Convenience. Owner may at any time, with or without cause, suspend, delay, reduce or interrupt performance of all or any portion of the Work for such period or periods as Owner elects (and without limitation of any of Owner's rights with respect to a breach or default by Contractor) by giving Contractor five (5) calendar days' written notice specifying which portion of the Work is to be suspended, delayed, reduced or interrupted and the effective date of same. Such suspension, delay, reduction or interruption shall continue until Owner terminates the same by written notice to Contractor. No such suspension, delay, reduction or interruption by Owner shall constitute a breach or default by Owner under the Contract Documents. Contractor shall continue to diligently perform any remaining Work that is not suspended, delayed, reduced or interrupted and shall take all actions necessary to maintain and safeguard all materials, equipment, supplies and Work in progress affected by the suspension, delay, reduction or interruption.
Sample 1
Owner’s Right To Suspend For Convenience. Owner may at any time, with or without cause, suspend, delay, reduce or interrupt performance of all or any portion of the Work for such period or periods as Owner elects by giving Contractor written notice specifying which portion of the Work is to be suspended and the effective date of such suspension. Such suspension, delay or interruption shall continue until Owner terminates such suspension, delay or interruption by written notice to Contractor; provided that if a suspension, delay or interruption of the entire Project (or such a substantial portion thereof that the suspension, delay or interruption with respect thereto would have a material adverse effect on the ability of Contractor to meet either the Original Project Guaranteed Date of Substantial Completion or the Expansion Project Guaranteed Date of Substantial Completion) shall continue for ninety (90) consecutive days or one hundred eighty (180) days in the aggregate, Contractor shall have the right to terminate this Contract upon giving Owner fourteen (14) business days’ written notice thereof and such termination shall be treated as a termination with cause for purposes of Section 17.6.2. No such suspension, delay, interruption or reduction by Owner shall constitute a breach or default by Owner under the Contract Documents. Contractor shall continue to diligently perform any remaining Work that is not suspended, delayed, reduced or interrupted and shall take all actions necessary to maintain and safeguard all materials, equipment, supplies and Work in progress affected by the suspension, delay, reduction or interruption.
Sample 1

Related to Owner’s Right To Suspend For Convenience

  • Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing. 2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Waiver of Right to Trial by Jury EACH PARTY TO THIS AGREEMENT HEREBY EXPRESSLY WAIVES ANY RIGHT TO TRIAL BY JURY OF ANY CLAIM, DEMAND, ACTION OR CAUSE OF ACTION ARISING UNDER ANY LOAN DOCUMENT OR IN ANY WAY CONNECTED WITH OR RELATED OR INCIDENTAL TO THE DEALINGS OF THE PARTIES HERETO OR ANY OF THEM WITH RESPECT TO ANY LOAN DOCUMENT, OR THE TRANSACTIONS RELATED THERETO, IN EACH CASE WHETHER NOW EXISTING OR HEREAFTER ARISING, AND WHETHER FOUNDED IN CONTRACT OR TORT OR OTHERWISE; AND EACH PARTY HEREBY AGREES AND CONSENTS THAT ANY SUCH CLAIM, DEMAND, ACTION OR CAUSE OF ACTION SHALL BE DECIDED BY COURT TRIAL WITHOUT A JURY, AND THAT ANY PARTY TO THIS AGREEMENT MAY FILE AN ORIGINAL COUNTERPART OR A COPY OF THIS SECTION WITH ANY COURT AS WRITTEN EVIDENCE OF THE CONSENT OF THE SIGNATORIES HERETO TO THE WAIVER OF THEIR RIGHT TO TRIAL BY JURY.

  • Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • Right to Specific Performance THE COMPANY HEREBY ACKNOWLEDGES AND AGREES THAT THE DAMAGES TO BE INCURRED BY PARTICIPANT AS A RESULT OF THE COMPANY’S BREACH OF THIS AGREEMENT WILL BE DIFFICULT, IF NOT IMPOSSIBLE, TO ASCERTAIN, THAT DAMAGES WILL NOT BE AN ADEQUATE REMEDY AND THAT ANY BREACH OR THREATENED BREACH OF ANY OF THE PROVISIONS OF THIS AGREEMENT BY THE COMPANY MAY CAUSE IMMEDIATE IRREPARABLE HARM FOR WHICH THERE MAY BE NO ADEQUATE REMEDY AT LAW. ACCORDINGLY, THE PARTIES AGREE THAT, IN THE EVENT OF ANY SUCH BREACH OR THREATENED BREACH, PARTICIPANT SHALL BE ENTITLED TO IMMEDIATE AND PERMANENT EQUITABLE RELIEF (INCLUDING INJUNCTIVE RELIEF AND SPECIFIC PERFORMANCE OF THE PROVISIONS OF THIS AGREEMENT) FROM A COURT OF COMPETENT JURISDICTION (IN ADDITION TO ANY OTHER REMEDY TO WHICH IT MAY BE ENTITLED AT LAW OR IN EQUITY). THE PARTIES AGREE AND STIPULATE THAT PARTICIPANT SHALL BE ENTITLED TO SUCH EQUITABLE (INCLUDING INJUNCTIVE) RELIEF WITHOUT POSTING A BOND OR OTHER SECURITY AND THE COMPANY FURTHER WAIVES ANY DEFENSE IN ANY SUCH ACTION FOR SPECIFIC PERFORMANCE OR INJUNCTIVE RELIEF THAT A REMEDY AT LAW WOULD BE ADEQUATE AND ANY REQUIREMENT UNDER LAW TO POST SECURITY AS A PREREQUISITE TO OBTAINING EQUITABLE RELIEF. NOTHING CONTAINED IN THIS SECTION SHALL LIMIT THE PARTIES’ RIGHT TO ANY REMEDIES AT LAW, INCLUDING THE RECOVERY OF DAMAGES FOR BREACH OF THIS AGREEMENT.

  • Right to Join Employees shall have the right to form and join labor or employee organizations, and shall have the right not to form and join such organizations. Employees in an appropriate unit shall have the right by secret ballot to designate an exclusive representative for the purpose of negotiating grievance procedures and the terms and conditions of employment for employees of such unit with the School Board.

  • No Waiver of Provisional Remedies, Self-Help and Foreclosure The arbitration requirement does not limit the right of any party to (i) foreclose against real or personal property collateral; (ii) exercise self-help remedies relating to collateral or proceeds of collateral such as setoff or repossession; or (iii) obtain provisional or ancillary remedies such as replevin, injunctive relief, attachment or the appointment of a receiver, before during or after the pendency of any arbitration proceeding. This exclusion does not constitute a waiver of the right or obligation of any party to submit any dispute to arbitration or reference hereunder, including those arising from the exercise of the actions detailed in sections (i), (ii) and (iii) of this paragraph.

  • Right to Refuse Unsafe Work Employees have the right to refuse to perform unsafe work pursuant to the Occupational Health and Safety Regulations of the Workers Compensation Act.

  • Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!