Owners Rights Responsibilities Sample Clauses

Open Split View

Download

Share

Cite

Owners Rights Responsibilities 

Sample 1

Save

Copy

Related to Owners Rights Responsibilities

• OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.

• CITY’S RESPONSIBILITIES 2.1. The CITY shall designate in writing a project coordinator to act as the CITY's representative with respect to the services to be rendered under this Agreement (the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define the CITY's policies and decisions with respect to the CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the CITY is obligated or committed to pay the CONTRACTOR. Any such modifications or changes ((a) (b) or (c)) shall only be made by or upon the authorization of the CITY’s city manager as authorized by city council in the enabling legislation or in the CITY’s procurement policies. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for the CONTRACTOR to enter the Project site to perform the services to be provided by the CONTRACTOR under this Agreement; and (c) Provide notice to the CONTRACTOR of any deficiencies or defects discovered by the CITY with respect to the services to be rendered by the CONTRACTOR hereunder. 2.3. The CONTRACTOR acknowledges that access to the Project Site, to be arranged by the CITY for the CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR.

• COUNTY’S RESPONSIBILITIES A. A County program liaison will monitor the submission of all correspondence required in this Agreement, including, but not limited to: 1. Quarterly Treatment Reports; 2. Financial reports such as annual budgets, cost allocation plans, and cost reports; 3. Incident reports; 4. Outcome data; 5. Monthly XXXXX Reports 6. Other requested reports B. A County program liaison may visit Contractor during the contract term. The visits shall be for the purpose of reviewing any aspect of Contractor’s program operations. The visit may include, but is not limited to: 1. Review all pertinent participant records. 2. Conduct appropriate interviews/discussions with participants served by Contractor. 3. Review and monitor all correspondence and reports submitted by Contractor related to Contractor’s services provided under this Agreement. 4. Meet with appropriate program management and operations staff. 5. Conduct site visit(s) to Contractor’s program(s) at least once during the term of the Agreement to review all aspects of program operations. Site visit(s) may include a review of Contractor’s programmatic and fiscal documentation related to required reports on services specified in the Exhibits. a. Provide a written site review report documenting areas of compliance and any necessary corrective action(s) required. 6. A County program liaison may attend an organized activity of a selected component or selected components of Contractor’s program(s) at least once during the contract term. C. AODS will conduct periodic mandatory treatment provider meetings with representatives of all contracted service providers and appropriate staff. D. Provide ongoing technical assistance as needed. E. AODS shall act as intermediary on behalf of each contracted alcohol and drug service provider in the submission of the California Outcomes Measurement System (CalOMS) data submissions to the State of California. I. GENERAL ADMINISTRATIVE REQUIREMENTS A. Attend each of the following meetings: 1. Contractor shall attend periodic mandatory meetings; and 2. Drug and Alcohol Information System for You (DAISY) User Group meeting. 3. Other meetings as required by the County B. Contractor shall acknowledge the San Mateo County Alcohol and Other Drug Services (AODS) and/or the County of San Mateo as a funding source on newly developed promotional materials. C. Subcontracting requirements: 1. Pursuant to paragraph 12 of the body of this Agreement, Contractor may subcontract for provision of services described in this Agreement with written approval of the Director of the Human Services Agency or her designee. If Contractor subcontracts for any services under this Agreement, Contractor will guarantee that any and all subcontractors have and maintain the same level of insurance coverage required of the Contractor under this Agreement. Contractor and County will be listed as additional insured on all applicable insurance of subcontractor.

• Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.

• ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages

• Client’s Responsibilities (a) Client agrees to advise Consultant regarding Client's Project requirements and to provide all relevant information, surveys, data and previous reports accessible to Client which Consultant may reasonably require. (b) Client shall designate a Project Representative to whom all communications from Consultant shall be directed and who shall have limited administrative authority on behalf of Client to receive and transmit information and make decisions with respect to the Project. Said representative shall not, however, have authority to bind Client as to matters of governmental policy or fiscal policy, nor to contract for additions or obligations exceeding a value which is the lesser of $5000 or 5% of the maximum contract price. (c) Client shall examine all documents presented by Consultant, and render decisions pertaining thereto within a reasonable time. The Client's approval of any drawings, specifications, reports, documents or other materials or product furnished hereunder shall not in any way relieve Consultant of responsibility for the professional adequacy of its work. (d) Client shall perform its obligations and render decisions within a reasonable time under the circumstances presented. Based upon the nature of Client and its requirements, a period of 14 days shall be presumed reasonable for any decision not involving policy decision or significant financial impact, when all information reasonably necessary for Client to responsibly render a decision has been furnished. A period of 46 days shall be presumed reasonable for Client to act with respect to any matter involving policy or significant financial impact. The above periods of presumed reasonableness shall be extended where information reasonably required is not within the custody or control of Client but must be procured from others.

• Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.

• Landlord’s Responsibilities (a) Landlord shall correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any non-compliance of the Building exterior and the Common Areas with all applicable building permits and codes in effect as of the Commencement Date, including, without limitation, the provisions of Title III of the Americans With Disabilities Act ("ADA") in effect as of the Commencement Date. Said costs of compliance shall be Landlord's sole cost and shall not be part of Project Costs. Landlord shall correct, repair or replace any non-compliance of the Building exterior and the Common Areas with any revisions or amendments to the ADA in effect after the Commencement Date, provided that the amortized cost of such repairs or replacements (amortized over the useful life thereof using a market cost of funds reasonably determined by Landlord) shall be included as Project Costs payable by Tenant. All other ADA compliance issues which pertain to the Premises, including, without limitation, in connection with Tenant's construction of any alterations or other improvements in the Premises (and any resulting ADA compliance requirements in the Common Areas), the Tenant Improvements and the operation of Tenant's business and employment practices in the Premises, shall be the responsibility of Tenant at its sole cost and expense. Landlord shall, during the initial Lease Term, correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any failure of the structural components of the roof, foundations, footings and load-bearing walls of the Building. The repairs, corrections or replacements required of Landlord or of Tenant under the foregoing provisions of this Section 2.4 shall be made promptly following notice of non-compliance from any applicable governmental agency. (b) Landlord warrants to Tenant that the Shell Building Improvements as defined in the Discovery Outline Specifications (as defined in the Work Letter) and the Tenant Improvements to be completed pursuant to the Work Letter shall be free from defects in workmanship or materials for a period of twelve (12) months from the Commencement Date. Landlord shall promptly rectify any non-compliance at its sole cost and expense after receipt of written notice from Tenant within such time setting forth the nature and extent of any such non-compliance. Landlord shall obtain customary warranties and guaranties from the contractor(s) performing the Tenant Improvement work and/or the manufacturers of equipment installed but shall be under no obligation to incur additional expense in order to obtain or extend such warranties. If after expiration of the initial twelve (12) months of the Lease Term, Tenant is required to make repairs to any component of the Premises or any of its systems for which Landlord may have obtained a warranty, Landlord shall, upon request by Tenant, use its good faith efforts to pursue its rights under any such warranties for the benefit of Tenant. Landlord shall be under no obligation to incur any expense in connection with asserting rights under such warranties or guaranties against either the contractor or the manufacturer, but shall use reasonable good faith efforts to enforce such warranties and guaranties for Tenant's benefit. (c) Notwithstanding the provisions of Section 7.2 of this Lease, Landlord agrees to maintain and repair, at its sole cost and expense and not as an Operating Expense the structural components of the roof and Building, including floor/ceiling slabs, columns, beams, walls and the foundations and footings of the Building during the initial Lease Term. If a non-compliance with the foregoing warranty exists, Landlord shall, promptly after receipt of the written notice from Tenant setting forth the nature and extent of such non-compliance, rectify same at Landlord's sole cost and expense.

• Company’s Responsibilities Except for the items above that are the responsibility of Authority, Company will, throughout the Term of this Agreement, assume full responsibility for all nonstructural repair and maintenance of the Premises, whether such repair or maintenance be ordinary or extraordinary, and without limiting the generality hereof, Company will keep the Premises and all of Company’s trade and other fixtures, equipment, and personal property that are located on any part of the Premises or Common Use Areas open to or visible by the general public, in a clean and orderly condition and appearance; and A. Provide and maintain required fire protection and safety equipment (other than that which Authority must provide in connection with construction of Authority’s improvements) and all other equipment of every kind and nature required by any law, rule, order, ordinance, resolution or regulation of any competent authority; and B. Keep all areas of the Premises in a state of good repair subject to reasonable wear and tear; and C. Repair any damage to the surfaces of the Premises and Common Use Areas caused by use of the surfaces in excess of the approved specifications and planned use or by any oil, gasoline, grease, lubricants or other liquids or substances having a corrosive or detrimental effect thereon; and D. Be responsible for the maintenance and repair of all utility service lines, except common utility lines, if any, including but not limited to, service lines for the supply of water, gas service lines, electrical power and telephone conduits and line, retention ponds, sanitary sewers and storm sewers that are now or that may be subsequently located upon the Premises or Common Use Areas and used by Company exclusively. E. All such maintenance, repair and replacements will be of quality equal to the condition of the Premises at the commencement of the Term of this Agreement.

• IRO Responsibilities The IRO shall: 1. perform each Claims Review in accordance with the specific requirements of the CIA;