Overtime Work Definition Overtime for non-exempt employees working any work schedule is actual time worked in excess of forty (40) hours per workweek.
Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
F3 Variation F3.1 The Authority may from time to time during the Contract Period, by written notice to the Contractor, request a variation of the Contract provided that such variation does not amount to a material change to it. Such a change is hereinafter called a “Variation”.
Concurrent Delay When the completion of the Work is simultaneously delayed by an excusable delay and a delay arising from a cause not designated as excusable, Contractor may not be entitled to a time extension for the period of concurrent delay.
Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.
NON-VARIATION No addition to or variation, consensual cancellation or novation of this agreement and no waiver of any right arising from this agreement or its breach or termination shall be of any force or effect unless reduced to writing and signed by all the parties or their duly authorised representatives.
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
Variation of period of parental leave Unless agreed otherwise between the employer and employee, an employee may apply to their employer to change the period of parental leave on one occasion. Any such change to be notified at least four weeks prior to the commencement of the changed arrangements.
Definition of Working Days Working day" as used in the Grievance and Arbitration procedure shall mean a day other than Saturday, Sunday or a recognized holiday.
Standard Work Week The standard work week shall be thirty-five (35) hours and is composed of five (5) consecutive standard work days.
