DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
SPECIAL DELIVERY INSTRUCTIONS All shipments will be FOB destination (as specified on Ordering Entity Purchase Order).
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
PRICE/DELIVERY Price(s) bid must be the price(s) for new goods, unless otherwise specified. Any bids containing modifying or “escalator” clauses will not be considered unless specifically requested in the bid specifications.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Late Delivery Supplier shall give DXC prompt notice of any prospective failure to ship Products or provide Services on the delivery date specified by DXC (the “Delivery Date”).
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000-000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent flooring inspector to verify the Warranty Holder’s warranty claims. The determination of the flooring inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/geowood-flooring-warranty/. Warranty Exclusions and Limitations: This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s GeoWood flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and (ii) maintained in accordance with Cali Bamboo’s GeoWood flooring care and maintenance guidelines found online at xxxxx://xxx.xxxxxxxxxx.xxx/floor-care-and-maintenance/ (the “Maintenance Guide”). Cali Bamboo will provide copies of these guides upon request by the Warranty Holder. This limited warranty only applies when the Flooring is used under normal traffic and other usage conditions. The limited warranty for Manufacturing Defects does not apply after the Warranty Holder has installed the Flooring, and product variation or error that does not exceed the 5% industry standard is not considered a Manufacturing Defect for purposes of this limited warranty. This limited warranty does not extend to or cover:
Delivery Terms All products sent to Customer shall be sent EX Works (EXW) or FCA Company’s facility in El Cajon, CA, and in domestic packing. Customer will bear and pay for all taxes of any nature imposed prior to, at the time of, or after delivery to, the carrier at the EXW point. Customer shall also bear and pay for all charges for freight, shipping, consular fees, customs duties, and all costs and charges. Customer must return the equipment in the same shipping container it was received in.
Delivery Times Deliveries to the City Warehouse or other designated City Buildings or Facilities will be accepted during normal working hours, i.e. 8:00a.m. to 4:00p.m., Monday through Friday unless other arrangements have been made. Deliveries being made directly to City work sites should be coordinated with the City employee responsible for the work being performed at that site.
