PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.
Payment for Working Overtime (a) For all work done outside ordinary hours, the rates of pay will be time and a half for the first two hours and double time thereafter. (b) Except as provided in clause 8.4, in computing overtime each day’s work will stand alone. (c) To avoid doubt, overtime provisions for shift workers are contained in clause 10.7.
Payment for Overtime 1. Except as provided in 2.C.3., below, overtime shall be compensated at one and one-half (1 1/2) times the regular rate. 2. Except as provided in 2.C.3., below, for all regular, limited-term and probationary employees, overtime may be converted to compensatory time or paid for at the option of the agency/department. Consideration shall be given to effectuating the wishes of employees. The maximum number of CTO hours which may be accrued by any employee is eighty (80). If an employee accrues 80 hours of CTO, he/she cannot accrue additional CTO until he/she uses some of the hours in his/her bank; instead, employees will be paid for all overtime work performed in excess of that amount. 3. Overtime hours worked by extra help employees shall be paid. 4. Compensatory time earned and accrued by an employee in excess of thirty-two (32) hours may be scheduled off for an employee by his or her agency/department; however, consideration shall be given to effectuating the wishes of those employees requesting specific compensatory time off periods. 5. No scheduled compensatory time off will be cancelled except in cases of emergency. 6. In no case may an employee's work schedule be changed during the workweek when the purpose of such change is to avoid overtime compensation. 7. Time worked as overtime shall not be used to earn fringe benefits or to serve out probation or merit increase periods. Compensatory time off may be used as part of the established workweek to earn fringe benefits and to serve out probationary and merit increase periods. 8. An employee separating from the County service shall be paid for accumulated compensatory time in a lump sum payment.
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $215,500.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Payment for Improvements If payment is made directly to contractors, Tenant shall (i) comply with Landlord's requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord an amount equal to five percent of the cost of such work to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord's involvement with such work. If Tenant does not order any work directly from Landlord, Tenant shall reimburse Landlord for Landlord's reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord's review of such work.
Time for Payment Interconnection Customer must provide the additional Security, in a form and with terms as required by Section 212.4, within 15 days after its receipt of Transmission Provider’s notice under this section. The requirement for additional Security under this section shall be treated as a milestone included in the Interconnection Service Agreement pursuant to Section 212.5.
Payment for Services Contractor shall exert reasonable and diligent efforts to collect prompt payment from the Commonwealth. Contractor shall pay Subcontractor in proportion to amounts received from the Commonwealth which are attributable to the Services performed by Subcontractor. Contractor shall pay Subcontractor within fourteen (14) days after the Contractor receives such payment from the Commonwealth, unless the parties expressly agree upon a different payment schedule or structure as set forth below: ______________________________________________________________________________________________________________________________________________________________________________________________________________________________________.
Reimbursement for Services Rendered If this Agreement is held to be invalid for any reason, and the Practice is required to refund fees, You agree to pay the Practice an amount equal to the fair market value of the medical services You received during the time period for which the refunded fees were paid.
Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.
Payment for TIPS Sales TIPS Members may make payments for TIPS Sales directly to Vendor, Vendor’s Authorized Reseller, or as otherwise agreed to in the applicable Supplemental Agreement after receipt of the invoice and in compliance with applicable payment statutes. Regardless of how payment is issued or received for a TIPS Sale, Vendor is responsible for all reporting and TIPS Administration Fee payment requirements as stated herein.
