PAYMENT TO SUB-CONTRACTORS 12.1 Transnet reserves the right, in its sole discretion, to make payment directly to the sub-contractor of the Supplier/Service Provider, subject to the following conditions:
a) Receipt of an undisputed invoice from the sub-contractor; and
b) Receipt of written confirmation from the Supplier/Service Provider that the amounts claimed by the sub-contractor are correct and that the services for which the sub- contractor has requested payment were rendered to the satisfaction of the Supplier/Service Provider, against the required standards.
12.2 Nothing contained in this clause must be interpreted as bestowing on any sub-contractor a right or legitimate expectation to be paid directly by Transnet. Furthermore, this clause does not bestow any right or legitimate expectation on the Supplier/Service provider to demand that Transnet pay its sub-contractor directly. The decision to pay any sub-contractor directly, remains that of Transnet alone.
Payment to Subcontractors (If applicable) As required by Minnesota Statute § 16A.1245, the prime Contractor must pay all subContractors, less any retainage, within 10 calendar days of the prime Contractor’s receipt of payment from the State for undisputed services provided by the subContractor(s) and must pay interest at the rate of one and one-half percent per month or any part of a month to the subContractor(s) on any undisputed amount not paid on time to the subContractor(s).
Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham.
(b) If the individual assigned to administer this contract for the City (in this section, titled “Prompt Payment to Subcontractors,” he or she will be referred to as the “Project Manager”) determines that it is appropriate to enforce subsection (a) in this manner, the City may withhold from progress or final payments to the Contractor the sums estimated by the Project Manager to be
(i) the amount of interest due to the Subcontractor under subsection (a), and/or
(ii) the amounts past-due under subsection (a) to the Subcontractor but not exceeding 5% of the payment(s) due from the City to the Contractor. This subsection (b) does not limit any other rights to withhold payments that the City may have.
(c) Nothing in this section (titled “Prompt Payment to Subcontractors”) shall prevent the Contractor at the time of invoicing, application, and certification to the City from withholding invoicing, application, and certification to the City for payment to the Subcontractor for unsatisfactory job progress; defective goods, services, or construction not remedied; disputed work; third-party claims filed or reasonable evidence that such a claim will be filed; failure of the subcontractor to make timely payments for labor, equipment, and materials; damage to the Contractor or another subcontractor; reasonable evidence that the subcontract cannot be completed for the unpaid balance of the subcontract sum; or a reasonable amount for retainage not to exceed 10%.
(d) The Project Manager may require, as a prerequisite to making progress or final payments, that the Contractor provide statements from any Subcontractors designated by the Project Manager regarding the status of their accounts with the Contractor. The statements shall be in such format as the Project Manager reasonably requires, including notarization if so specified.
Your Legal Power to Sign and Invest You have the legal power to sign this Investment Agreement and purchase the Note.
Payments to Subcontractors Develop and implement a procedure for the review, processing and payment of applications by subcontractors for progress and final payments.
Agreement to Subordinate The Company agrees, and each Holder by accepting a Note agrees, that the Indebtedness evidenced by the Notes is subordinated in right of payment, to the extent and in the manner provided in this Article 10, to the prior payment in full of all Senior Debt (whether outstanding on the date hereof or hereafter created, incurred, assumed or guaranteed), and that the subordination is for the benefit of the holders of Senior Debt.
Payment of GST Payment of the additional amount will be made at the same time as payment for the supply is required to be made under this Contract.
Consent to Suit In the case of any dispute under or in connection with this Agreement, the Indemnitee may only bring suit against the Corporation in the Court of Chancery of the State of Delaware. The Indemnitee hereby consents to the exclusive jurisdiction and venue of the courts of the State of Delaware, and the Indemnitee hereby waives any claim the Indemnitee may have at any time as to forum non conveniens with respect to such venue. The Corporation shall have the right to institute any legal action arising out of or relating to this Agreement in any court of competent jurisdiction. Any judgment entered against either of the parties in any proceeding hereunder may be entered and enforced by any court of competent jurisdiction.
Agreement to Serve The Indemnitee agrees to serve and/or continue to serve as agent of the Company, at its will (or under separate agreement, if such agreement exists), in the capacity Indemnitee currently serves as an agent of the Company, so long as he is duly appointed or elected and qualified in accordance with the applicable provisions of the Bylaws of the Company or any subsidiary of the Company or until such time as he tenders his resignation in writing; provided, however, that nothing contained in this Agreement is intended to create any right to continued employment by Indemnitee.
Trustee to Sign Amendments The Trustee shall sign any amendment authorized pursuant to this Article 9 if the amendment does not adversely affect the rights, duties, liabilities or immunities of the Trustee. If it does, the Trustee may but need not sign it. In signing such amendment the Trustee shall be entitled to receive indemnity reasonably satisfactory to it and to receive, and (subject to Section 7.01) shall be fully protected in relying upon, an Officers' Certificate and an Opinion of Counsel stating that such amendment is authorized or permitted by this Indenture.
