Payments to Contractor. For and in consideration of the faithful performance of the work herein embraced as set forth in the Contract Documents, and in accordance with the directions of the TOWN, through its Engineer and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final completion and acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) of the amount of any subsequent progress payments made under the Contract may be retained, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in the Contract, except as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontract.
Appears in 10 contracts
Samples: Construction, Construction, Construction
Payments to Contractor. For On or before the last Monday of each and in consideration of every month during the faithful performance of the work herein embraced as set forth in Work, CONTRACTOR shall meet with the Contract DocumentsProject Manager or his or her designee to determine the quantity of pay items incorporated into the improvement during that month. A “Progress Payment Order” will then be jointly prepared, approved, and in accordance with signed by the directions of the TOWN, through its Engineer Project Manager and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final completion and acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than paid and providing for a five percent (5%) retention. Upon approval of the amount of any subsequent progress payments made under payment order by the Contract may be retainedProject Manager, providing the CONTRACTOR is making satisfactory progress on the projector his or her designee, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention it shall be reinstated submitted to CITY’s Finance Department and processed for all progress payments made under payment by obtaining approval from the Contract subsequent City Council to issue a warrant. Within three (3) days following City Council’s approval to issue a warrant, CITY shall mail to CONTRACTOR a warrant for the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately amount specified in the Contract, except progress payment order as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site amount to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineerpaid. Ten percent (10%) (or The retained five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty thirty-five (6035) days after completion or filing notice of completion the recording of the Contract. Retention Notice of payments Completion of the Work by the TOWN longer than sixty (60) days COUNTY and after final completion CONTRACTOR shall have furnished releases of all claims against CITY by persons who furnished labor or materials for the Work, if required by CITY. Upon the request of CONTRACTOR and acceptance requires a specific written finding by at its expense, securities equivalent to the TOWN amount withheld pursuant to the foregoing provisions may be presented to CITY for substitution for the retained funds. If CITY approves the form and amount of the reasons justifying offered securities it will release the delay retained funds and will hold the securities in paymentlieu thereof. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to any interest earned on the securities. In the event that claims for property damage or bodily injury are presented to CITY arising out of CONTRACTOR’s or any subcontractor’s Work under this Agreement; CITY shall give notice thereof to CONTRACTOR, and CONTRACTOR shall have thirty-five (35) days from the mailing of any such notice to evaluate the claim and to settle it by whole or partial payment, or to reject it, and to give notice of settlement or rejection to CITY. If CITY does not receive all interest notice within the above-mentioned 35-day period that the claim has been settled, and if the Project Manager, after consultation with the City Attorney, determines that the claim is meritorious, CITY may pay the claim or income earned by such security as a portion of it accrues in exchange for an appropriate release from the claimant, and may deduct the amount of the payment from the retained funds that would otherwise be paid to CONTRACTOR upon completion of the Work; provided, however, that the maximum amount paid for any one claim pursuant to this provision shall be One Thousand Dollars ($1,000.00), and the maximum amount for all such security claims in lieu of retention the aggregate paid pursuant to this provision shall be returned to the CONTRACTOR by the TOWN within sixty Five Thousand Dollars (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontract$5,000.00).
Appears in 4 contracts
Samples: Public Works Agreement, Public Works Agreement, Public Works Agreement
Payments to Contractor. For and in consideration of Partial payments will be made as the faithful performance of the work herein embraced as set forth in the Contract Documents, and in accordance with the directions of the TOWN, through its Engineer and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished Work progresses at the unit bid price end of each calendar month, or as soon thereafter as practicable, on estimates made by the Owners' authorized representative and as approved by the Owner, provided the Contractor is performing the overall job in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutesa diligent manner. In making partial payments, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments there shall be retained 5 percent on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final substantial completion of all work covered by this Contract, in order to insure proper performance of the Contract. Payments, as approved by the Owner's authorized representative, shall be made to the Contractor by the Owner no later than the 15th day of each calendar month for work performed the preceding month provided the Contractor submits data so required by the Owner's authorized representative to the Owner's authorized representative by the 5th day of each calendar month. The computation of quantities that will be the basis for estimates, both monthly and final, shall be made by the Owner's authorized representative in accordance with methods defined in the Contract Documents. In preparing estimate data to be submitted to the Owner's authorized representative, Contractor may include for consideration material properly delivered and stored on site and any preparatory work. All material and work covered by partial payments made shall thereupon become the sale property of the Owner, but this provision shall not be construed as relieving the Contractor from the sole responsibility for the care and protection of materials and work upon which payments have been made or the restoration of any damaged work, or as a waiver of the right of the Owner to require the fulfillment of all of the terms of the Contract. Upon completion and acceptance of all materialthe Work, equipment the Owner's authorized representative shall issue a certificate that the Work has been completed and work covered accepted by him under the Contract. An conditions of this contract, and shall make and approve the final estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the ContractWork. The TOWN entire balance found to be due the Contractor, including retained percentages, but excepting such sums as may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received lawfully retained by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth belowOwner, shall be paid to the CONTRACTOR Contractor. Such payment shall be conditioned, however, upon submission by the Contractor of evidence satisfactory to the Owner that all claims for labor, material and other outstanding indebtedness in connection with this Contract have been paid. If, after the Work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor and the Owner's authorized representative so certifies, the Owner shall upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) certificate of the amount of any subsequent progress payments made under the Contract may be retainedOwner's authorized representative, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in without terminating the Contract, except make payment for the balance-due for that portion of the Work fully completed and accepted. The Owner's authorized representative may withhold or, on account of subsequently discovered evidence, nullify the whole or part of any estimate to such extent as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay protect the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens Owner from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontract.loss on account of:
Appears in 1 contract
Samples: Proposal Contract
Payments to Contractor. For and in consideration 14.1 CONTRACTOR will not be entitled to any money for any work performed before the issuance of a Notice to Proceed on the faithful performance of the work herein embraced as set forth form described in the Contract DocumentsDocuments and the issuance by City Manager of a “purchase order”, or any other document, does not and in accordance with will not authorize the directions commencement of the TOWNWork. At least ten (10) calendar days before each progress payment falls due (but not more often than once a month), through its Engineer CONTRACTOR must submit to CONSULTANT a partial payment estimate filled out and to its satisfactionsigned by CONTRACTOR covering the Work performed during the period covered by the partial payment estimate and supported by such data as CONSULTANT may reasonably require. All progress payment applications after the first progress payment must be accompanied by partial releases of lien executed by all persons, the TOWN agrees to pay the CONTRACTOR the amount earnedfirms and corporations who have furnished labor, computed from actual quantities of work performed and accepted services or materials furnished at incorporated into the unit bid price in work during the Bid Proposal period of time for which the previous progress payment was made, releasing such claims and to make such lien rights, if any, of those persons. If payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR is requested on the basis of a duly certified materials and approved equipment not incorporated in the Work but delivered and suitably stored at or near site, the partial payment estimate must also be accompanied by such supporting data, satisfactory to the City Manager, which establishes OWNER’s title to the material and equipment as well as certificates of insurance providing coverage for 100% of the work performed during the preceding calendar month under such Contract may include payment for value of said material and equipmentequipment covering the material and equipment from all casualties as well as theft, but vandalism, fire and flood. CONTRACTOR must replace at its expense any stored materials paid for which are either damaged or stolen before installation. CONSULTANT will within ten (10) calendar days after receipt of each partial payment estimate, either certifying in writing its approval of payment and present the partial payment estimate to ensure the proper performance City Manager, or return the partial payment estimate to CONTRACTOR, indicating in writing his reasons for refusing to approve payment. In the latter case, CONTRACTOR may make the necessary corrections and resubmit the partial payment estimate. OWNER, will within thirty (30) calendar days of such Contractpresentation to it of any approved partial payment estimate, pay CONTRACTOR a progress payment on the TOWN shall basis of the approved partial payment estimate. City Manager may retain ten per cent (10%) percent of the amount of each estimate payment until final completion Final Completion and acceptance Acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) of the amount of any subsequent progress payments made under the Contract may be retained, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in the Contract, except as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work Work covered by the Contract if Documents. Any interest earned on the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship retainage will accrue to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part benefit of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the SubcontractOWNER.
Appears in 1 contract
Samples: Construction Contract
Payments to Contractor. For (a) Within the first fifteen (15) days of each calendar month, the Owner shall make partial payment to the Contractor for construction accomplished which includes cleanup during the preceding calendar month on the basis of completed Assembly Units invoiced by and in consideration certified to by the Contractor, recommended by the Engineer and approved by the Owner solely for purposes of payment. Provided, however, that such approval shall not be deemed approval of the faithful performance workmanship or materials. Only ninety-five percent (95%) of each such invoice approved during the construction of the work herein embraced project shall be paid by the Owner to the Contractor prior to completion of the Contract. Upon completion by the Contractor of the construction of the Project, the Engineer will prepare a Final Inventory of the project showing the total number of and character of Assembly Units and, after checking such Inventory with the Contractor, will certify it to the Owner, together with a certificate of the total cost of the construction performed. Upon the approval of such certificates by the Owner, the Owner shall make payment to the Contractor of all amounts to which the Contractor shall be entitled thereunder which shall not have been paid: Provided, however, that such final payment shall be made not later than ninety (90) days after the date of completion of construction of the Project, as specified in the Certificate of Completion, unless withheld because of the fault of the Contractor. For purposes of payment pursuant to this Article III, Section 1(a), "Construction Accomplished" shall not include the delivery to the Project Site of cable, wire, and conduit materials for appropriate Assembly Units. Provided, however, that payments to the Contractor for such cable, wire, and conduit materials delivered to the Project Site shall be made to the extent that the aggregate amount of all such payments shall not exceed eighty percent (80%) of the material costs, as set forth in the Contract Documentsassembly unit prices, up to a maximum $1,000,000. The payments shall be considered due and payable when placement of cable, wire, and in accordance with the directions of the TOWN, through its Engineer and to its satisfaction, the TOWN agrees to pay the CONTRACTOR conduit materials begin. When the amount earnedof cable, computed from actual quantities of work performed wire, and accepted or conduit materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment delivered to the CONTRACTOR on Project Site exceed the basis of a duly certified $1,000,000 initial payment or additional cable, wire, and approved estimate of conduit materials are delivered to the work performed during Project Site subsequent to the preceding calendar month under such Contract may include payment for material and equipmentinitial payment, but additional payments will be made up to ensure the proper performance of such Contract, the TOWN shall retain ten per cent eighty percent (1080%) of the amount of each estimate until final completion and acceptance of all materialmaterial unit prices, equipment and work covered by the Contract. An estimate only after $100,000 or more of the work submitted cable, wire, and conduit materials have been incorporated into the Project. Payments made on account of such material shall be deemed approved and certified for payment after ten (10) days subtracted from the date monthly estimates of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) of the amount of any subsequent progress payments made under the Contract may be retained, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in the Contract, except as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontractcompleted Assembly Units.
Appears in 1 contract
Samples: Construction Agreement
Payments to Contractor. For On or before the last Monday of each and in consideration of every month during the faithful performance of the work herein embraced as set forth in Work, CONTRACTOR shall meet with the Contract DocumentsProject Manager or his or her designee to determine the quantity of pay items incorporated into the improvement during that month. A “Progress Payment Order” will then be jointly prepared, approved, and in accordance with signed by the directions of the TOWN, through its Engineer Project Manager and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final completion and acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than paid and providing for a five percent (5%) retention. Upon approval of the amount of any subsequent progress payments made under payment order City Hall Fire Alarm System Upgrade Project – Phase II by the Contract may be retainedProject Manager, providing the CONTRACTOR is making satisfactory progress on the projector his or her designee, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention it shall be reinstated submitted to CITY’s Finance Department and processed for all progress payments made under payment by obtaining approval from the Contract subsequent City Council to issue a warrant. Within three (3) days following City Council’s approval to issue a warrant, CITY shall mail to CONTRACTOR a warrant for the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately amount specified in the Contract, except progress payment order as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site amount to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineerpaid. Ten percent (10%) (or The retained five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty thirty-five (6035) days after completion or filing notice of completion the recording of the Contract. Retention Notice of payments Completion of the Work by the TOWN longer than sixty (60) days COUNTY and after final completion CONTRACTOR shall have furnished releases of all claims against CITY by persons who furnished labor or materials for the Work, if required by CITY. Upon the request of CONTRACTOR and acceptance requires a specific written finding by at its expense, securities equivalent to the TOWN amount withheld pursuant to the foregoing provisions may be presented to CITY for substitution for the retained funds. If CITY approves the form and amount of the reasons justifying offered securities it will release the delay retained funds and will hold the securities in paymentlieu thereof. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to any interest earned on the securities. In the event that claims for property damage or bodily injury are presented to CITY arising out of CONTRACTOR’s or any subcontractor’s Work under this Agreement; CITY shall give notice thereof to CONTRACTOR, and CONTRACTOR shall have thirty-five (35) days from the mailing of any such notice to evaluate the claim and to settle it by whole or partial payment, or to reject it, and to give notice of settlement or rejection to CITY. If CITY does not receive all interest notice within the above-mentioned 35-day period that the claim has been settled, and if the Project Manager, after consultation with the City Attorney, determines that the claim is meritorious, CITY may pay the claim or income earned by such security as a portion of it accrues in exchange for an appropriate release from the claimant, and may deduct the amount of the payment from City Hall Fire Alarm System Upgrade Project – Phase II the retained funds that would otherwise be paid to CONTRACTOR upon completion of the Work; provided, however, that the maximum amount paid for any one claim pursuant to this provision shall be One Thousand Dollars ($1,000.00), and the maximum amount for all such security claims in lieu of retention the aggregate paid pursuant to this provision shall be returned to the CONTRACTOR by the TOWN within sixty Five Thousand Dollars (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontract$5,000.00).
Appears in 1 contract
Samples: Public Works Agreement
Payments to Contractor. For and in consideration of the faithful performance of Partial payments will be made as the work herein embraced as set forth in the Contract Documents, and in accordance with the directions of the TOWN, through its Engineer and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished progresses at the unit bid price end of each calendar month, or as soon thereafter as practicable, on estimates made by the owners' authorized representative and as approved by the owner, provided the Contractor is performing the overall job in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutesa diligent manner. In making partial payments, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments there shall be retained 5 percent on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final substantial completion of all work covered by this Contract, in order to insure proper performance of the Contract. Payments, as approved by the owner's authorized representative, shall be made to the Contractor by the Owner no later than the 15th day of each calendar month for work performed the preceding month provided the Contractor submits data so required by the Owner's authorized representative to the Owner's authorized representative by the 5th day of each calendar month. The computation of quantities that will be the basis for estimates, both monthly and final, shall be made by the owner's authorized representative in accordance with methods defined in the Contract Documents. In preparing estimate data to be submitted to the owner's authorized representative, Contractor may include for consideration material properly delivered and stored on site and any preparatory work. All material and work covered by partial payments made shall thereupon become the sale property of the owner, but this provision shall not be construed as relieving the Contractor from the sole responsibility for the care and protection of materials and work upon which payments have been made or the restoration of any damaged work, or as a waiver of the right of the Owner to require the fulfillment of all of the terms of the Contract. Upon completion and acceptance of all materialthe work, equipment and work covered by the Contract. An estimate of owner's authorized representative shall issue a certificate that the work submitted shall be deemed approved has been completed and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment accepted by him under the Contract. The TOWN may withhold any amount from conditions of this contract, and shall make and approve the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the final estimate of the work. When The entire balance found to be due the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retainedContractor, including any securities substituted retained percentages, but excepting such sums as set forth belowmay be lawfully retained by the owner, shall be paid to the CONTRACTOR Contractor. Such payment shall be conditioned, however, upon submission by the Contractor of evidence satisfactory to the Owner that all claims for labor, material and other outstanding indebtedness in connection with this Contract have been paid. If, after the work has been substantially completed, full completion thereof is materially delayed through no fault of the Contractor and the owner's authorized representative so certifies, the owner shall upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) certificate of the amount of any subsequent progress payments made under the Contract may be retainedOwner's authorized representative, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in without terminating the Contract, except make payment for the balance-due for that portion of the work fully completed and accepted. The Owner's authorized representative may withhold or, on account of subsequently discovered evidence, nullify the whole or part of any estimate to such extent as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay protect the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens owner from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontract.loss on account of:
Appears in 1 contract
Samples: Proposal Contract
Payments to Contractor. For GC Section 9 is amended and supplemented as follows: Copies of all Applications for Payment shall be submitted to Owner and Architect no later than the twenty-fifth (25th) day of any calendar month for any period preceding such date. Notwithstanding anything to the contrary in consideration of the faithful performance of Construction Documents, the work herein embraced parties acknowledge that Architect will not review or issue Certificates for Payment, and that Owner shall be entitled to review all Applications for Payment without consulting with Architect. Owner shall be entitled to withhold amounts included in an Application for Payment if Owner does not approve such amount as set forth in this Section 9. Contractor shall submit to Owner the Application for Payment and all notices and documents required in the Contract Documents to be provided to Architect in connection with its review of the Application for Payment or the issuance of a Certificate for Payment. If requested by Owner, each Application for Payment (after the first) shall be accompanied by an accounting of the disbursement of funds previously received by Contractor from Owner, certified to be true and correct by Contractor. Upon the reasonable request of Owner, such accounting also shall itemize all disbursements to Subcontractors and Suppliers and Contractor shall deliver to Owner copies of all vendors' invoices, payroll and other data substantiating actual expenditures by Contractor for the Work, and upon reasonable request, shall allow Owner to inspect the books and records of Contractor relating to such expenditures. In each Application for Payment, Contractor shall certify that: (i) the requested payment represents a just determination of the actual amount payable to Contractor under the Contract Documents, and in accordance with ; (ii) the directions of the TOWN, through its Engineer and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the work. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of the amount of each estimate until final completion and acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency information set forth in the written finding. The progress payments shall be paid on or before fourteen Application for Payment is correct; (14iii) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid to the CONTRACTOR upon the CONTRACTOR’s request, provided the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) of the amount of any subsequent progress payments made under the Contract may be retained, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract subsequent to the determination. Upon completion and acceptance of each separate building, public work or other division of the Contract on which the price is stated separately in the Contract, except as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to the best of Contractor's knowledge, is in full force and effect and free from default by any party (or if Owner is in default, the nature of the default); (iv) any contingency reserve under the Contract has or has not been utilized, and if utilized, the amount that remains; (v) all Subcontractors and Suppliers have been paid all sums that are due and payable to them in full (excluding payments due which are included in the Application for Payment in question); (vi) Contractor shall promptly pay all sums due and payable to Subcontractors, unions, laborers, and Suppliers out of funds to be received pursuant to the Application for Payment; (vii) no Lien currently affects the Work nor is there any basis for the filing of a Lien with respect to Work, other than Liens caused solely by Owner's wrongful withholding of amounts due Contractor under the Contract or Liens for the Work included in the Application for Payment; (viii) all amounts due and payable with respect to the Work either have been paid to the CONTRACTOR within sixty (60) days after completion date or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN included in the finding justifying Application for Payment; and (ix) partial waivers of mechanic's liens totaling the retention of moneys. In lieu of the retention provided amounts previously paid by Owner to Contractor have been obtained from all Subcontractors and Suppliers in this sectionsuch form as to constitute an effective waiver, the TOWN shallunder applicable Law, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned Lien rights with respect to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the SubcontractWork.
Appears in 1 contract
Samples: Vivus Inc
Payments to Contractor. For (a) Within the first fifteen (15) days of each calendar month, the Owner shall make partial payment to the Contractor for construction accomplished, which includes cleanup, during the preceding calendar month on the basis of completed Assembly Units invoiced by and in consideration certified to by the Contractor, recommended by the Engineer, and approved by the Owner solely for purposes of payment. Provided, however, that such approval shall not be deemed approval of the faithful performance workmanship or materials. Only ninety-five percent (95%) of each such invoice approved during the construction of the work herein embraced project shall be paid by the Owner to the Contractor prior to completion of Construction of the Contract. Upon completion by the Contractor of the construction of the Project, the Engineer will prepare a Final Inventory of the project showing the total number of and character of Assembly Units and, after checking such Inventory with the Contractor, will certify it to the Owner, together with a certificate of the total cost of the construction performed. Upon the approval of such certificates by the Owner, the Owner shall make payment to the Contractor of the amounts to which the Contractor shall be entitled thereunder which shall not have been paid: Provided, however, that such final payment shall be made not later than ninety (90) days after the date of completion of construction of the Project, as specified in the Certificate of Completion, unless withheld because of the fault of the Contractor. For purposes of payment pursuant to this Article III, Section 1(a), "Construction Accomplished" shall not include the delivery to the Project Site of cable materials for the appropriate Assembly Units. Provided, however, that payments to the Contractor for such cable materials delivered to the Project Site shall be made to the extent that the aggregate amount of such payments shall not exceed eighty percent (80%) of the material costs, as set forth in the Contract Documentsassembly unit prices, up to a maximum $500,000. The payments shall be considered due and in accordance with the directions payable when placement of the TOWN, through its Engineer wire and to its satisfaction, the TOWN agrees to pay the CONTRACTOR the amount earned, computed from actual quantities of work performed and accepted or materials furnished at the unit bid price in the Bid Proposal and to make such payment in accordance with applicable Arizona Revised Statutes, after final inspection and acceptance of the workcable begins. The TOWN by mutual agreement may make progress payments on contracts of less than ninety days and shall make monthly progress payments on all other contracts as provided for in this paragraph. Payment to the CONTRACTOR on the basis of a duly certified and approved estimate of the work performed during the preceding calendar month under such Contract may include payment for material and equipment, but to ensure the proper performance of such Contract, the TOWN shall retain ten per cent (10%) of When the amount of each estimate until final completion wire and acceptance of all material, equipment and work covered by the Contract. An estimate of the work submitted shall be deemed approved and certified for payment after ten (10) days from the date of submission unless before that time the TOWN or TOWN’s agent prepares and issues a specific written finding setting forth those items in detail in the estimate of the work that are not approved for payment under the Contract. The TOWN may withhold any amount from the progress payment sufficient to pay the expenses the TOWN reasonably expects to incur in correcting the deficiency set forth in the written finding. The progress payments shall be paid on or before fourteen (14) days after the estimate of the work is certified and approved. The estimate of the work shall be deemed received by the TOWN on submission to any person designated by the TOWN for the submission, review or approval of the estimate of the work. When the Contract is fifty per cent (50%) completed, one-half (1/2) of the amount retained, including any securities substituted as set forth below, shall be paid cable materials delivered to the CONTRACTOR upon Project Site exceed the CONTRACTOR’s request, provided $500,000 initial payment or additional wire and cable are delivered to the CONTRACTOR is making satisfactory progress on the Contract and there is no specific cause or claim requiring a greater amount to be retained. After the Contract is fifty per cent (50%) completed, no more than five percent (5%) of the amount of any subsequent progress payments made under the Contract may be retained, providing the CONTRACTOR is making satisfactory progress on the project, except that if at any time the TOWN determines satisfactory progress is not being made, ten per cent (10%) retention shall be reinstated for all progress payments made under the Contract Project Site subsequent to the determination. Upon completion and acceptance of each separate buildinginitial payment, public work or other division additional payments will be made up to 80% of the Contract material unit prices, only after $100,000 or more of the wire and cable materials have been incorporated into the Project. Payments made on which the price is stated separately in the Contract, except as qualified below, payment may be made in full, including retained percentages thereon, less authorized deductions. In preparing estimates, the account of such material and equipment delivered on the site to be incorporated in the job shall be taken into consideration in determining subtracted from the estimated value by the Architect or Engineer. Ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) if monthly estimates of all estimates shall be retained by the TOWN as a guarantee for complete performance of the Contract, to be paid to the CONTRACTOR within sixty (60) days after completion or filing notice of completion of the Contract. Retention of payments by the TOWN longer than sixty (60) days after final completion and acceptance requires a specific written finding by the TOWN of the reasons justifying the delay in payment. The TOWN may not retain any moneys after sixty (60) days which are in excess of the amount necessary to pay the expenses the purchasing agency reasonably expects to incur in order to pay or discharge the expenses determined by the TOWN in the finding justifying the retention of moneys. In lieu of the retention provided in this section, the TOWN shall, at the option of the CONTRACTOR, accept as a substitute an assignment of time certificates of deposit of banks licensed by this State, securities of or guaranteed by the United States of America, securities of this State, securities of counties, municipalities and schools within this State, or shares of savings and loan institutions authorized to transact business in this State, in an amount equal to ten per cent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) of all estimates which shall be retained by the agent as a guarantee for complete performance of the Contract. In the event the TOWN accepts substitute security as described in this paragraph for the ten percent (10%) (or five percent (5%) the CONTRACTOR is making satisfactory progress) retention, the CONTRACTOR shall be entitled to receive all interest or income earned by such security as it accrues and all such security in lieu of retention shall be returned to the CONTRACTOR by the TOWN within sixty (60) days after final completion and acceptance of all material, equipment and work covered by the Contract if the CONTRACTOR has furnished the TOWN satisfactory receipts for all labor and material billed and waivers of liens from any and all persons holding claims against the work. In no event shall the agent accept a time certificate of deposit of a bank or shares of a savings and loan institution in lieu of the retention specified unless accompanied by a signed and acknowledged waiver of the bank or savings and loan association of any right or power to set off against either the TOWN or the CONTRACTOR in relationship to the certificates or shares assigned. In any instance where the TOWN has accepted substitute security as provided above, any Subcontractor undertaking to perform any part of such public work shall be entitled to provide substitute security to the CONTRACTOR upon terms and conditions similar to those described above, and such security shall be in lieu of any retention under the Subcontractcompleted Assembly Units.
Appears in 1 contract