Performance Excused by Occurrence of Uncontrollable Force. 13.6.1 Neither Party shall be considered to be in default in the performance of any of its obligations under This Agreement when a failure of performance is due to an Uncontrollable Force.
Performance Excused by Occurrence of Uncontrollable Force Sample Clauses
Related to Performance Excused by Occurrence of Uncontrollable Force
Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Limit on Operating Expenses The Advisor hereby agrees to limit the Fund’s current Operating Expenses to an annual rate, expressed as a percentage of the Fund’s average daily net assets for the month, to the amounts listed in Appendix A (the “Annual Limit”). In the event that the current Operating Expenses of the Fund, as accrued each month, exceed its Annual Limit, the Advisor will pay to the Fund, on a monthly basis, the excess expense within the first ten days of the month following the month in which such Operating Expenses were incurred (each payment, a “Fund Reimbursement Payment”).
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Operating Expense Limit The Fund’s maximum operating expense limits (each an “Operating Expense Limit”) in any year shall be that percentage of the average daily net assets of the Fund as set forth on Schedule A attached hereto and incorporated by this reference.
Maximum Annual Operating Expense Limit The Maximum Annual Operating Expense Limit with respect to each Fund shall be the amount specified in Schedule A based on a percentage of the average daily net assets of each Fund.
Statement of Actual Direct Expenses and Payment by Tenant Landlord shall give to Tenant within five (5) months following the end of each Expense Year, a statement (the “Statement”) which shall state the Direct Expenses incurred or accrued for such preceding Expense Year, and which shall indicate the amount of Tenant’s Share of Direct Expenses. Upon receipt of the Statement for each Expense Year commencing or ending during the Lease Term, Tenant shall pay, with its next installment of Base Rent due that is at least thirty (30) days thereafter, the full amount of Tenant’s Share of Direct Expenses for such Expense Year, less the amounts, if any, paid during such Expense Year as “Estimated Direct Expenses,” as that term is defined in Section 4.4.2, below, and if Tenant paid more as Estimated Direct Expenses than the actual Tenant’s Share of Direct Expenses, Tenant shall receive a credit in the amount of Tenant’s overpayment against Rent next due under this Lease. The failure of Landlord to timely furnish the Statement for any Expense Year shall not prejudice Landlord or Tenant from enforcing its rights under this Article 4. Even though the Lease Term has expired and Tenant has vacated the Premises, when the final determination is made of Tenant’s Share of Direct Expenses for the Expense Year in which this Lease terminates, Tenant shall immediately pay to Landlord such amount, and if Tenant paid more as Estimated Direct Expenses than the actual Tenant’s Share of Direct Expenses, Landlord shall, within thirty (30) days, deliver a check payable to Tenant in the amount of the overpayment. The provisions of this Section 4.4.1 shall survive the expiration or earlier termination of the Lease Term.
Financial Covenant Required Actual Complies Adjusted Quick Ratio 1.05:1.00 ____:1.00 Yes No Maintain on a Quarterly Basis: Minimum EBITDA Fiscal Quarter End Minimum EBITDA Yes No March 28, 2014 ($17,000,000) June 27, 2014* ($27,000,000) September 26, 2014* ($12,000,000) December 26, 2014* ($8,000,000) March 27, 2015* ($3,000,000) June 26, 2015* $1.00 September 25, 2015 and thereafter* TBD *measured on a trailing two fiscal quarter basis The following financial covenant analys[is][es] and information set forth in Schedule 1 attached hereto are true and accurate as of the date this Certificate is delivered to Bank as set forth in the first line of this Certificate. The following are the exceptions with respect to the certification above: (If no exceptions exist, state “No exceptions to note.”) ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------ ADMINISTRATIVE BORROWER: AVIAT NETWORKS, INC. By: ______________________________ Name: ________________________ Title: ________________________ BANK USE ONLY Received by: _________________________ AUTHORIZED SIGNER Date: _______________________________ Verified: ____________________________ AUTHORIZED SIGNER Date: _______________________________ Compliance Status: Yes No Schedule 1 to Compliance Certificate Financial Covenants of Borrower In the event of a conflict between this Schedule and the Loan Agreement, the terms of the Loan Agreement shall govern. Dated: ____________________
Total Operating Expenses All costs and expenses paid or incurred by the Company, as determined under GAAP, that are in any way related to the operation of the Company or its business, including the Advisory Fee, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and taxes incurred in connection with the issuance, distribution, transfer and registration of securities, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines; (vi) acquisition fees and Acquisition Expenses, (vii) real estate commissions on the sale of Real Property, and (viii) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgages or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair, and improvement of property). The definition of “Total Operating Expenses” set forth above is intended to encompass only those expenses which are required to be treated as Total Operating Expenses under the NASAA REIT Guidelines. As a result, and notwithstanding the definition set forth above, any expense of the Company which is not part of Total Operating Expenses under the NASAA REIT Guidelines shall not be treated as part of Total Operating Expenses for purposes hereof. 2%/25% Guidelines. 2%/25% Guidelines shall have the meaning set forth in Section 14.
