PERFORMANCE OF LAYOUT WORK BY LANDLORD'S CONTRACTORS. The performance ---------------------------------------------------- of the Layout Work shall be governed by this Paragraph 5.
PERFORMANCE OF LAYOUT WORK BY LANDLORD'S CONTRACTORS Sample Clauses
Related to PERFORMANCE OF LAYOUT WORK BY LANDLORD'S CONTRACTORS
Services by Landlord As long as Tenant is not in default hereunder, Landlord agrees to furnish those services and utilities to the Premises, which are customarily provided to tenants in comparable suburban office buildings located in the West Fort Worth area, and which shall specifically include the services listed on Exhibit “G” (attached hereto and made a part hereof for all purposes). All of such services shall be provided at Landlord’s cost and expense during Normal Business Hours except as specifically provided to the contrary elsewhere in this Lease. Services provided at times other than during Normal Business Hours shall be at Tenant’s cost and expense, with such charges to be established by Landlord, in Landlord’s sole discretion, and reimbursed to Landlord on demand. Failure to any extent to furnish or any stoppage of said utilities and services resulting from any cause whatsoever (a “Service Failure”) shall not render Landlord liable in any respect for damages to either person, property or business, nor be construed as an eviction of Tenant, nor entitle Tenant to any abatement of rent, nor relieve Tenant from fulfillment of any covenant or agreement contained herein. Should any malfunction of the Building improvements or facilities (which by definition do not include any improvements or facilities of Tenant besides Building standard improvements) occur for any reason (a “Malfunction”), Landlord shall use reasonable diligence to repair same promptly, but Tenant shall have no claim for rebate or abatement of rent or damages on account of such Malfunction or of any Service Failure occasioned thereby or resulting therefrom. Any provision herein to the contrary notwithstanding, if a Malfunction or Service Failure results in the Premises or any material portion thereof not being reasonably usable by Tenant for its business purpose (“Untenantable”) (unless the Service Failure is caused by a fire or other casualty, in which event Paragraph 22 hereof controls) and same remains uncured for a total of 5 consecutive days after Landlord’s receipt of Tenant’s written notice of the Malfunction or Service Failure, Tenant shall have the following rights and remedies: (a) Effective on the first day after the 5th consecutive day following such Malfunction or Service Failure, Tenant shall be entitled to an equitable abatement of Base Rental and Additional Rental commensurate to that portion of the Premises rendered Untenantable by the Malfunction or Service Failure calculated on a per square foot basis and ending at the time the Premises are again suitable for use by Tenant for its intended purposes.
ACCESS BY LANDLORD Under the terms of this Lease, access to the Property by Landlord may be undertaken as follows: A. The Tenant shall not unreasonably withhold consent to the Landlord to enter the dwelling unit from time to time in order to inspect the Property; make necessary or agreed repairs, decorations, alterations, or improvements; supply agreed services; or exhibit the dwelling unit to prospective or actual purchasers, mortgagees, tenants, workers, or contractors. B. Landlord may enter the dwelling unit at any time for the protection or preservation of the Property. Landlord may enter the dwelling unit upon reasonable notice to the Tenant and at a reasonable time for the purpose of repair of the Property. 'Reasonable notice' for the purpose of repair is notice given at least 24 hours prior to the entry, and reasonable time for the purpose of repair shall be between the hours of 7:30 a.m. and 8:00 p.m. Landlord may enter the dwelling unit when necessary for the further purposes set forth above under any of the following circumstances: a. With the consent of the Tenant b. In case of emergency c. When the Tenant unreasonably withholds consent d. If the Tenant is absent from the Property for a period of time equal to one-half the time for periodic rental payments. If the Rent is current and the Tenant notifies Landlord of an intended absence, then the Landlord may enter only with the consent of the Tenant or for the protection or preservation of the Property. C. The Landlord shall not abuse the right of access nor use it to harass the Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work. Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
Repairs by Landlord Landlord shall keep the roof, exterior walls, exterior building windows, public corridors, equipment used in common with other tenants (such as elevators, plumbing, heating, air-conditioning and similar equipment) and the structural components of the Building in a good state of repair, and shall accomplish such repairs as may be needed within fifteen (15) days after receipt of written notice from Tenant (except in emergencies or cases of urgent necessity (when such repairs shall be commenced immediately) and such longer time as is reasonably required to adequately remedy the problem provided the remedy has begun and Landlord is diligently prosecuting the same to completion). Notwithstanding anything herein to the contrary, Landlord shall have no obligation to repair any latent defects (i) capable of detection in the ordinary course of Tenant's business and first detected more than one (1) year after the Commencement Date or (ii) that have no material adverse effect on Tenant's ability to conduct business in or gain access to the Premises. Nothing herein shall diminish Tenant's obligation to maintain and repair any special equipment installed in the Leased Premises or Building specifically for Tenant, including without limitation any telecommunication equipment, security equipment, computer equipment, kitchen equipment, any Tenant HVAC System or any Tenant Generator. If repairs are required by reason of Tenant's acts or negligent failure to act, Tenant shall promptly pay Landlord, as additional rent, for the cost thereof. Except as otherwise specifically provided in Sections 15 or 18 below, there shall be no abatement of rent and no liability of Landlord by reason of any injury to or interference with Tenant's business arising from the making of any repairs, alterations or improvements in or to any portion of the Leased Premises or building of which the Leased Premises are a part, or in or to fixtures, appurtenances and equipment therein. In no event shall Landlord be liable to Tenant for any damage to the Leased Premises or for any loss, damage or injury to any property therein or thereon resulting from acts by other third parties or occasioned by fire; explosion; falling plaster; the breaking, bursting, stoppage or leaking of water, gas, sewer, electrical cables, wires or steam pipes; or from water, rain, or other substances leaking or coming from the roof, street, subsurface or from any other place or from dampness or from any similar risks or causes. Landlord shall not be liable for any loss or damage to any person or property sustained by Tenant or any other persons, which may be caused by theft, or by any act or neglect of any tenant or occupant of the Project, or of any other third parties.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
Maintenance by Landlord Tenant and its employees, customers and licensees shall have the non-exclusive right to use the parking areas, if any, as may be designated by Landlord in writing, subject to such reasonable rules and regulations as Landlord may from time to time prescribe. Further, in multiple occupancy buildings, Landlord shall perform the roof, paving, and landscape maintenance, exterior painting and common sewage line plumbing which are otherwise Tenant's obligations under Subsection 2.2.2(a) above, and Tenant shall, in lieu of the obligations set forth under Subsection 2.2.2(a) above with respect to such items, be liable for its proportionate share (as defined in Subsection 2.2.1(b) above) of the cost and expense of Building maintenance and the care for the grounds around the Building, including but not limited to, the mowing of grass, care of shrubs, general landscaping, maintenance of parking areas, driveways and alleys, roof maintenance, exterior repainting and common sewage line plumbing; provided, however, that Landlord shall have the right to require Tenant to pay such other reasonable proportion of said mowing, shrub care and general landscaping costs as may be determined by Landlord in its sole discretion; and further provided that if Tenant or any other particular tenant of the Building can be clearly identified as being responsible for obstruction or stoppage of the common sanitary sewage line then Tenant, if Tenant is responsible, or such other responsible tenant, shall pay the entire cost thereof, upon demand, as additional rent. Tenant shall pay/4// when due its share, determined as aforesaid, of such costs and expenses along with the other tenants of the Building to Landlord upon demand, as Additional Rent, for the amount of its share of such costs and expenses in the event Landlord elects to perform or cause to be performed such work. Such share shall include a management fee equal to five percent (5%) of the Rent for each Lease Year, administrative and accounting costs, and a/5// reserve for asphalt, roof repairs and repainting.
Lessee Improvements Lessee shall prepare final plans and ------------------- specifications for construction of the Lessee Improvements desired by Lessee and shall deliver to Lessor by July 1, 1999, two (2) copies of such plans and specifications and the names of two proposed contractors to construct the Lessee Improvements for Lessor approval. Lessor will promptly either approve of the plans and specifications and the contractors, or communicate its objections, and if Lessor has objections, the Lessor will work diligently with Lessee to resolve any objections such that approval of the plans and specifications and names of contractors is given within fifteen (15) days of receipt. Lessor shall be deemed to have approved the plans and specifications and the contractors unless Lessor shall have provided written notice to Lessee of Lessor's objections thereto within fourteen (14) days following the delivery thereof by Lessee to Lessor. The Lessor approved final plans and specifications for the Lessee Improvements are herein called the "Lessee Improvements Final Plans and Specifications". All reasonable costs involved in approving, drafting and preparing the Lessee Improvements Final Plans and Specifications shall be charged against the Improvement Allowance described below. Lessor shall apply for building permits to construct the Lessee Improvements and will submit bid requests to the two contractors selected by Lessee and the contractor for the Shell Building Improvements no later than two (2) days following approval of the Lessee Improvements Final Plans and Specifications. Contractors will be required to submit their bids no later than thirty (30) days following receipt of the bid request. Lessee shall have fifteen (15) days from receipt of all bids to select the contractor for the Lessee Improvements. Except for immaterial field changes, modifications to the Lessee Improvements Final Plans and Specifications must be made and accepted only by written change order or agreement signed by Lessor and Lessee and will constitute an amendment to this Lease. Lessee shall be responsible for payment in advance of all work and construction resulting from changes in the Lessee Improvements Final Plans and Specifications requested by Lessee if the additional cost attributable to the changes exceed the Improvement Allowance by more than $3.00 as described in subparagraph (c) below. The Lessee Improvements Final Plans and Specifications (when approved by Lessor and Lessee) are incorporated in this Lease by reference. For the purpose of this Section, an "immaterial field change" shall mean such field changes which are required by any governmental authority or changes which (i) do not affect the size, configuration, structural integrity, quality, character, architectural appearance and standard of workmanship contemplated in the Lessee Improvements Final Plans and Specifications, (ii) will not result in any default in any obligation to any person or violation of any governmental requirements, and (iii) the cost of or reduction resulting from any single field change or extra does not exceed $5,000.00.
Performance by Landlord If Tenant fails to perform any obligation required under this Lease or by law or governmental regulation, Landlord in its sole discretion may, after ten (10) days prior written notice to Tenant, without waiving any rights or remedies and without releasing Tenant from its obligations hereunder, perform such obligation, in which event Tenant shall pay Landlord as additional rent all sums paid by Landlord in connection with such substitute performance, including interest at the Agreed Interest Rate (as defined in Section 19.J) within ten (10) days of Landlord's written notice for such payment.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
