Authority’s Obligations Save as otherwise expressly provided, the obligations of the Authority under the Contract are obligations of the Authority in its capacity as a contracting counterparty and nothing in the Contract shall operate as an obligation upon, or in any other way xxxxxx or constrain the Authority in any other capacity, nor shall the exercise by the Authority of its duties and powers in any other capacity lead to any liability under the Contract (howsoever arising) on the part of the Authority to the Contractor.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Conditions to Each Party’s Obligation The respective obligation of each party to effect the transactions contemplated by this Agreement is subject to the satisfaction or waiver, on or prior to the Closing Date, of the following conditions:
Conditions to Each Party’s Obligations The obligations of each Party to consummate the Merger and the other transactions described herein shall be subject to the satisfaction or written waiver (where permissible) by the Company and the Purchaser of the following conditions:
City’s Obligations A. Following the execution of this Agreement, the CITY shall begin efforts to implement the activities described in Article I of this Agreement. The failure by the CITY to develop and implement the activities described in Article I of this Agreement shall constitute a breach of this Agreement. The CITY understands and agrees that, in the event termination of this Agreement by CITY, or pursuant to Article V of this Agreement, the CITY shall reimburse the IDC the full amount of money paid by the IDC to the CITY.
B. In accordance with Chapter 2264 of the Texas Government Code, the CITY agrees not to knowingly employ an undocumented worker. During the term of this Agreement, the CITY shall notify the IDC of any complaint brought against CITY alleging that it has employed undocumented workers. If the CITY, or any branch, division or department of the CITY is convicted of a violation under 8 U.S.C. Section 1324a (f), the total amount of economic development grants it has received, together with interest at the rate of five percent (5%), shall be repaid by the CITY to the IDC not later than the one hundred twentieth (120th) day after the date the IDC becomes aware of and notifies the CITY of the violation. The CITY shall not be liable for a violation of Chapter 2264 by a subsidiary, affiliate, or franchisee, or by any person with whom the CITY contracts. The CITY shall reimburse the IDC the required amount within thirty (30) days of the termination of this Agreement. The CITY further certifies that CITY is following Texas Government Code Chapter 2252 (foreign terrorist organizations prohibited), Texas Government Code Chapter 2270 (boycott-Israel), and Texas Government Code Chapter 2274, (boycotts-energy company; discrimination – firearms entity or trade association).
C. The CITY shall keep and maintain complete and accurate records relating to its hiring and employment of persons, which is separate and identifiable from its other records, and shall make such records available for not less than three (3) years following termination of this Agreement. The IDC and its representatives shall be entitled to inspect said records during the term of this Agreement and for three (3) years thereafter, upon reasonable notice to the CITY. The CITY’s failure to comply with this provision will constitute a breach of the Agreement.
Conditions of Company's Obligations The Company’s obligation to issue and sell the Securities to the Purchaser on the Closing Date is subject to the fulfillment prior to or on the Closing Date of the following conditions, any of which may be waived in whole or in part by the Company:
Performance of the Agreement 2.1 The Designer must make every effort to perform the work commissioned carefully and independently, to promote the client’s interests to the best of his or her ability and to aim to achieve a result that is useful to the client, as can and may be expected of a reasonably and professionally acting designer. To the extent necessary the Designer must keep the client informed of the progress of the work.
2.2 The client must do any and all things that are reasonably necessary or required to enable the Designer to deliver punctually and properly, such as supplying (or causing the supply of) complete, sound and clear data or materials in a timely manner of which the Designer states or of which the client understands or should reasonably understand that they are necessary for the performance of the agreement.
2.3 Terms stated by the Designer for the performance of the work commissioned are approximations only, unless otherwise agreed in writing.
2.4 Unless otherwise agreed, the following do not form part of the work commissioned to the Designer:
a. performing tests, applying for permits and assessing whether the client’s instructions comply with statutory or quality standards;
b. investigating any existing rights, including patents, trademarks, drawing or design rights or portrait rights of third parties; and
c. investigating the possibility of the forms of protection referred to in (b) for the Client.
2.5 Prior to performance, production, reproduction or publication, the parties must give each other the opportunity to check and approve the final draft, prototypes or galley proofs of the result.
2.6 Differences between the (final) result and the agreements made cannot serve as grounds for rejection, discount, damages or dissolution of the agreement if those differences are reasonably of minor importance, taking all the circumstances into account.
2.7 Any complaints must be filed with the Designer in writing at the earliest possible time but no later than ten business days after completion of the work commissioned, failing which the client is deemed to have accepted the result of the work commissioned in its entirety.
Performance of Borrowers’ Obligations Agent may, in its discretion at any time and from time to time, at Borrowers’ expense, pay any amount or do any act required of a Borrower under any Loan Documents or otherwise lawfully requested by Agent to (a) enforce any Loan Documents or collect any Obligations; (b) protect, insure, maintain or realize upon any Collateral; or (c) defend or maintain the validity or priority of Agent’s Liens in any Collateral, including any payment of a judgment, insurance premium, warehouse charge, finishing or processing charge, or landlord claim, or any discharge of a Lien. All payments, costs and expenses (including Extraordinary Expenses) of Agent under this Section shall be reimbursed to Agent by Borrowers, on demand, with interest from the date incurred to the date of payment thereof at the Default Rate applicable to Base Rate Revolver Loans. Any payment made or action taken by Agent under this Section shall be without prejudice to any right to assert an Event of Default or to exercise any other rights or remedies under the Loan Documents.
Conditions of Parties Obligations 7.1 Conditions of Investor's Obligations at the Closing. The --------------------------------------------------- obligation of Investor to purchase and pay for the Investor Stock is subject to the fulfillment prior to or on the Closing Date of the following conditions, any of which may be waived in whole or in part by Investor:
Developer’s Obligations 7.1.1 In consideration of the Rights hereby granted, the Developer shall pay to the Authority an annual fee of Rs. /- (Rupees only) (“Fee”) commencing from the 1st (first) anniversary of Appointed Date. The Fee is exclusive of GST and all other applicable taxes and shall be payable by the Developer at actual over and above the Fee. The Fee is payable to the Authority on or before 30 (thirty) days prior to the start of every year in advance as set out in Schedule 1 throughout the Agreement Period. During the Agreement Period the Fee shall be increased by 5% (five percent) every year over the previous year’s Fee on compounded basis.
7.1.2 The Developer should pay the Fee to the Authority notwithstanding the fact that, the development of Project Facilities is not completed within the specified period or Developer does not start the commercial operation of the Project. In other words, the Developer shall not be entitled to seek any reduction of Fee, claim, damages, compensation or any other consideration from the Authority on account of any reason.
7.1.3 Any delay in payment of the Fee shall attract an interest for the delayed period at the rate of SBI PLR plus 5% per annum on the outstanding amount, which shall be due from the date of such payment till the amount is realized by the Authority. In addition to the foregoing, any delay in payment of Fee beyond a period of 60 (sixty) days from the due date of such payment will be construed to be Material Breach under this Agreement.
