Performance Standards, Actual Damages, Liquidated Damages, and Penalties Sample Clauses

Performance Standards, Actual Damages, Liquidated Damages, and Penalties a. Performance Bond/Irrevocable Bank Letter of Credit DOM shall require a Performance Bond or Irrevocable Bank Letter of Credit, as outlined in Section 6.5.3 of the RFP. These sureties provide security to DOM throughout the course of this Contract. The bond must provide funds to DOM for any liability, loss, damage, or expense as a result of the Contractor’s failure to perform fully and completely all requirements of this Contract. Such requirements include, but are not limited to, the Contractor’s obligation to pay liquidated damages, indemnify DOM under circumstances described in this Contract, and the Contractor’s obligation to perform the services required by this Contract throughout the entire term of the Contract. The Written Dollar Amount shall not be reduced at any time during the period of the Contract without written agreement by both parties. The Contractor shall secure and submit the bond prior to the start date of contract negotiations and in the manner and form prescribed by DOM. The bond shall be issued through a company licensed to issue such a bond in the State of Mississippi. The adequacy of the Performance Bond or Irrevocable Bank Letter of Credit will be determined at DOM’s sole discretion. The Performance Bond or Irrevocable Bank Letter of Credit shall cover the entire Contract period, including all options to extend this Contract, and shall not be released until final acceptance of all products and deliverables required herein or until the Warranty period has expired, whichever occurs last, in order to guarantee full and faithful performance of all undertakings and obligations under this Contract. At DOM’s sole discretion, DOM may, at any time during the Warranty period, review Contractor’s performance in order to determine that the Performance Bond or Irrevocable Bank Letter of Credit may be reduced or released prior to expiration of the Warranty period. The Contractor must make all necessary arrangements for the Performance Bond or Irrevocable Bank Letter of Credit prior to the start date of Contract negotiations. Contractor acknowledges and understands that DOM will not assist the Contractor with securing the services of any fidelity or guaranty underwriter. Failure to adhere to the requirements of this section shall result in termination of this Contract as a material breach of the Contract.
Sample 1
AutoNDA by SimpleDocs

Related to Performance Standards, Actual Damages, Liquidated Damages, and Penalties

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.

  • Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.

  • Deduction of Damages from Contract Price Upon prior written notice being issued to the Contractor, CMHA may deduct all or any part of the damages resulting from Contractor’s default from any part of the price still due on this Agreement.

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Compensation for Damages and Losses Investors of either Contracting Party whose investments suffer losses in the territory of the other Contracting Party owing to war or other armed conflict, revolution, a state of national emergency or revolt, shall be accorded treatment by such other Contracting Party not less favourable than that which the latter Contracting Party accords to its own investors or to investors of any third State as regards restitution, indemnification, compensation or other valuable consideration.

  • Arbitration, Damages, Warranties Notwithstanding any language to the contrary, no interpretation of this contract shall find that the State or its agencies have agreed to binding arbitration, or the payment of damages or penalties. Further, the State of Kansas and its agencies do not agree to pay attorney fees, costs, or late payment charges beyond those available under the Kansas Prompt Payment Act (K.S.A. 75-6403), and no provision will be given effect that attempts to exclude, modify, disclaim or otherwise attempt to limit any damages available to the State of Kansas or its agencies at law, including but not limited to the implied warranties of merchantability and fitness for a particular purpose.

  • Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!