Permit Termination Right Sample Clauses

Permit Termination Right. Either Party has the right to terminate this Agreement on Notice, which will be effective five (5) Business Days after such Notice is given, if Seller has not obtained permits necessary for the construction and operation of the Project within twenty-two (22) months after the Execution Date [For Category 3 Projects that do not have an Active Interconnection Study prior to the Execution Date: Interconnection Study Completion Date] and a Notice of termination is given on or before the end of the twenty-third (23rd) month after the Execution Date [For Category 3 Projects that do not have an Active Interconnection Study prior to the Execution Date: Interconnection Study Completion Date]; provided that prior to any termination by Seller under this Section 13.10, Seller must have taken all commercially reasonable actions (including but not limited to Seller’s timely filing of required documents and payment of all applicable fees) to obtain such permits.
Sample 1Sample 2Sample 3See All (14)
AutoNDA by SimpleDocs
Permit Termination Right. Either Party has the right to terminate this Agreement on Notice, which will be effective five (5) Business Days after such Notice is given, if Seller has not obtained permits necessary for the construction and operation of the Project within twenty-two (22) months after the Execution Date and a Notice of termination is given on or before the end of the twenty-third (23rd) month after the Execution Date; provided that prior to any termination by Seller under this Section 14.10, Seller must have taken all commercially reasonable actions (including but not limited to Seller’s timely filing of required documents and payment of all applicable fees) to obtain such permits.
Sample 1Sample 2Sample 3See All (11)
Permit Termination Right. Either Party has the right to terminate this Agreement on Notice, which will be effective five (5) Business Days after such Notice is given, if Seller has not obtained permits necessary for the construction and operation of the Project within thirty-four (34) months after the [Execution Date] [For Category 3 Projects that do not have an Active Interconnection Study prior to the Execution Date: Interconnection Study Completion Date] and a Notice of termination is given on or before the end of the thirty-fifth (35th) month after the [Execution Date] [For Category 3 Projects that do not have an Active Interconnection Study prior to the Execution Date: Interconnection Study Completion Date]; provided that prior to any termination by Seller under this Section 13.10, Seller must have taken all commercially reasonable actions (including but not limited to Seller’s timely filing of required documents and payment of all applicable fees) to obtain such permits. SCHEDULING COORDINATOR; FORECASTING PENALTIES; CAISO CHARGES; GOVERNMENTAL CHARGES
Sample 1
Permit Termination Right. Either Party has the right to terminate this Agreement on Notice, which will be effective five (5) Business Days after such Notice is given, if Seller has not obtained permits necessary for the construction and operation of the Project within thirty-four
Sample 1
Permit Termination Right. Either Party has the right to terminate this Agreement on Notice, which will be effective five (5) Business Days after such Notice is given, if Seller has not obtained permits necessary for the construction and operation of the Project within twenty- two (22) months after the [For Category 3 Projects that do not have an active interconnection queue position number: “Interconnection Study Completion Date”; for all other Projects: “Execution Date”] and a Notice of termination is given on or before the end of the twenty-third (23rd) month after the [For Category 3 Projects that do not have an active interconnection queue position number: “Interconnection Study Completion Date”; for all other Projects: “Execution Date”]; provided that prior to any termination by Seller under this Section 13.10, Seller must have taken all commercially reasonable actions (including but not limited to Seller’s timely filing of required documents and payment of all applicable fees) to obtain such permits.
Sample 1

Related to Permit Termination Right

  • Termination Right The Representative shall have the right to terminate this Agreement at any time prior to any Closing Date, (i) if any domestic or international event or act or occurrence has materially disrupted, or in its opinion will in the immediate future materially disrupt, general securities markets in the United States; or (ii) if trading on any Trading Market shall have been suspended or materially limited, or minimum or maximum prices for trading shall have been fixed, or maximum ranges for prices for securities shall have been required by FINRA or by order of the Commission or any other government authority having jurisdiction, or (iii) if the United States shall have become involved in a new war or an increase in major hostilities, or (iv) if a banking moratorium has been declared by a New York State or federal authority, or (v) if a moratorium on foreign exchange trading has been declared which materially adversely impacts the United States securities markets, or (vi) if the Company shall have sustained a material loss by fire, flood, accident, hurricane, earthquake, theft, sabotage or other calamity or malicious act which, whether or not such loss shall have been insured, will, in the Representative’s opinion, make it inadvisable to proceed with the delivery of the Securities, or (vii) if the Company is in material breach of any of its representations, warranties or covenants hereunder, or (viii) if the Representative shall have become aware after the date hereof of such a material adverse change in the conditions or prospects of the Company, or such adverse material change in general market conditions as in the Representative’s judgment would make it impracticable to proceed with the offering, sale and/or delivery of the Securities or to enforce contracts made by the Underwriters for the sale of the Securities.

  • Termination Rights This Agreement may be terminated at any time prior to the Closing:

  • Complete Disposal Upon Termination of Service Agreement Upon Termination of the Service Agreement Provider shall dispose or delete all Student Data obtained under the Service Agreement. Prior to disposition of the data, Provider shall notify LEA in writing of its option to transfer data to a separate account, pursuant to Article II, section 3, above. In no event shall Provider dispose of data pursuant to this provision unless and until Provider has received affirmative written confirmation from LEA that data will not be transferred to a separate account.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!