Permitted Schedule Amendments. The Company may, from time to time, amend the Project Schedule to extend the Scheduled Completion Date, but (except as permitted in the following sentence) not beyond Outside Completion Deadline, by delivering to the Disbursement Agent a Project Budget/Schedule Amendment Certificate (a) containing a revised Project Schedule reflecting the new Scheduled Completion Date and (b) complying with the provisions of

Permitted Schedule Amendments. The Borrower may, from time to time, amend the Project Schedule to extend the Anticipated Substantial Operations Date (but (except as permitted in the following sentence) not beyond the Outside Substantial Operations Deadline) or, for any particular Active Phase, to extend the Anticipated Opening Date or the Anticipated Completion Date for such Phase (but (except as permitted in the following sentence) not beyond the applicable Outside Opening Deadline (if any) or Outside Completion Deadline), by delivering to the Administrative Agent a Project Budget/Schedule Amendment Certificate (a) containing a revised Project Schedule reflecting the new Anticipated Opening Date, the new Anticipated Substantial Operations Date or the new Anticipated Completion Date of such Phase, as the case may be, and (b) complying with the provisions of subsection 7.19(A)(ii) above with respect to the changes in the Project Budget that will result from the extension of the Anticipated Opening Date, the Anticipated Substantial Operations Date or the Anticipated Completion Date of such Phase. If an Event of Loss or an Event of Force Majeure occurs with respect to any Phase, then the Borrower shall be permitted to extend the Outside Substantial Operations Deadline, the Outside Opening Deadline (if any) or the Outside Completion Deadline, as the case may be, to the extent that the Borrower certifies in writing, and the Construction Consultant confirms, to the Administrative Agent that such extension is reasonably necessary to overcome any delays caused by the Event of Loss or Event of Force Majeure and the Borrower remains In Balance, provided that no such extension may extend beyond three hundred sixty-five (365) calendar days.

Permitted Schedule Amendments. (a) The Company may, from time to time, amend the Project Schedules (i) to extend the Phase I Scheduled Opening Date, the Phase I Scheduled Substantial Completion Date or the Phase I Scheduled Completion Date, but not beyond the Outside Phase I Opening Deadline, the Outside Phase I Substantial Completion Deadline and the Outside Phase I Completion Deadline, respectively, and/or (ii) to extend the Phase II Scheduled Opening Date or the Phase II Scheduled Completion Date but not beyond the Outside Phase II Opening Deadline and the Outside Phase II Completion Deadline, respectively, by delivering to the Disbursement Agent a Project Budget/Schedule Amendment Certificate (a) containing a revised Project Schedule reflecting the new Phase I Scheduled Opening Date, Phase I Scheduled Substantial Completion Date, Phase I Scheduled Completion Date, Phase II Scheduled Opening Date or Phase II Scheduled Completion Date, as the case may be, and (b) complying with the provisions of Section 6.3.1

Permitted Schedule Amendments. If an Event of Loss or an Event of Force Majeure occurs, LCR and the Phase II Mall Borrowers may, from time to time, amend the Project Schedule to extend the Outside Completion Deadline, but not beyond twelve (12) months after the Outside Completion Deadline in effect on the Effective Date by delivering to the Disbursement Agent a Project Budget/Schedule Amendment Certificate (a) containing a revised Project Schedule reflecting the new Outside Completion Deadline, (b) complying with the provisions of Section 6.3.1(b) with respect to the changes in the Project Budget that will result from the extension of the Outside Completion Deadline; and (c) containing a certification by LCR and the Phase II Mall Borrowers, confirmed by the Construction Consultant in a certificate attached thereto, that the proposed extension is reasonably necessary to overcome any delays caused by the Event of Loss or Event of Force Majeure, provided, however, in no event shall the foregoing amendment affect the Phase II Mall Outside Substantial Completion Date unless expressly permitted under the Phase II Mall Purchase Agreement or otherwise consented to by the Phase II Mall Buyer.

Permitted Schedule Amendments. (a) The Company may, from time to time, amend the Phase II Project Schedule to extend the Phase II Scheduled Opening Date or the Phase II Scheduled Completion Date but not beyond the Outside Phase II Opening Deadline and the Outside Phase II Completion Deadline, respectively, by delivering to the Disbursement Agent a Project Schedule Amendment Certificate (i) containing a revised Phase II Project Schedule reflecting the new Phase II Scheduled Opening Date or Phase II Scheduled Completion Date, as the case may be, and (ii) complying with the provisions of Section 6.3.1(c) with respect to the changes in the Phase II Project Budget that will result from such extension. (b) If an Event of Force Majeure occurs, then the Company shall be permitted to extend the Outside Phase II Opening Deadline to the extent that the Company certifies in writing to the Disbursement Agent that such extension is reasonably necessary to overcome any delays caused by the Event of Force Majeure, provided that no such extension may extend beyond March 31, 2010. If an Event of Force Majeure occurs, then the Company shall be permitted to extend the Outside Phase II Completion Deadline to the extent that the Company certifies in writing to the Disbursement Agent that such extension is reasonably necessary to overcome any delays caused by the Event of Force Majeure, provided that no such extension may extend beyond June 30, 2010.

Related to Permitted Schedule Amendments

Supplements and Amendments This Agreement may be amended by the Depositor and the Owner Trustee, without the consent of any of the Noteholders or the Certificateholder, to cure any ambiguity, to correct or supplement any provisions in this Agreement or for the purpose of adding any provisions to or changing in any manner or eliminating any of the provisions in this Agreement or of modifying in any manner the rights of the Noteholders or the Certificateholder; provided, however, that such action shall not, as evidenced by an Opinion of Counsel, adversely affect in any material respect the interests of any Noteholder or the Certificateholder, provided further that 10 days’ (or, in the case of Fitch, 10 Business Days’) prior written notice of any such amendment be made available to each Rating Agency by the Administrator and, if Moody’s notifies the Owner Trustee that such amendment will result in a downgrading or withdrawal of the then-current rating of any class of the Notes, such amendment shall become effective with the consent of the Holders of Notes evidencing not less than a majority of the Outstanding Amount of the Notes; provided further that any solicitation of such consent shall disclose the downgrading or withdrawal that would result from such amendment. This Agreement may also be amended from time to time by the Depositor and the Owner Trustee, with prior written notice made available to the Rating Agencies by the Administrator, with the consent of the Holders of Notes evidencing not less than a majority of the Outstanding Amount of the Notes and the consent of the Certificateholder (which consents will not be unreasonably withheld) for the purpose of adding any provisions to or changing in any manner or eliminating any of the provisions of this Agreement or of modifying in any manner the rights of the Noteholders or the Certificateholder; provided, however, that no such amendment shall (a) increase or reduce in any manner the amount of, or accelerate or delay the timing of, collections of payments on Receivables or distributions that shall be required to be made for the benefit of the Noteholders or the Certificateholder or (b) reduce the aforesaid percentage of the Outstanding Amount of the Notes required to consent to any such amendment or eliminate the consent of the Certificateholder to any such amendment, without the consent of the holders of all the outstanding Notes and the Certificate. Promptly after the execution of any such amendment or consent, the Owner Trustee shall furnish written notification of the substance of such amendment or consent to the Certificateholder, the Indenture Trustee and the Administrator, which shall make such notification available to each of the Rating Agencies. It shall not be necessary for the consent of the Certificateholder, the Noteholders or the Indenture Trustee pursuant to this Section to approve the particular form of any proposed amendment or consent, but it shall be sufficient if such consent shall approve the substance thereof. Promptly after the execution of any amendment to the Certificate of Trust, the Owner Trustee shall cause the filing of such amendment with the Secretary of State. Prior to the execution of any amendment to this Agreement or the Certificate of Trust, the Owner Trustee shall be entitled to receive and rely upon an Opinion of Counsel stating that the execution of such amendment is authorized or permitted by this Agreement and that all conditions precedent to the execution of such amendment have been satisfied. The Owner Trustee may, but shall not be obligated to, enter into any such amendment which affects the Owner Trustee’s own rights, duties or immunities under this Agreement or otherwise.
Supplements and Amendments; Whole Agreement This Warrant may be amended or supplemented only by an instrument in writing signed by the parties hereto. This Warrant contains the full understanding of the parties hereto with respect to the subject matter hereof and thereof and there are no representations, warranties, agreements or understandings other than expressly contained herein and therein.
Amendments, Supplements and Waivers The Company and the Trustee may amend or supplement the Indenture or the Notes or waive compliance with any provision of the Indenture or the Notes in the manner, and subject to the terms, set forth in Section 7.05 and Article 8 of the Indenture.
Conforming Amendments The Agreement, the Loan Documents and all agreements, instruments and documents executed and delivered in connection with any of the foregoing, shall each be deemed to be amended and supplemented hereby to the extent necessary, if any, to give effect to the provisions of this Amendment. The Agreement and the other Loan Documents shall remain in full force and effect in accordance with their respective terms.
Amendments to Schedules The Schedules to this Agreement form an integral part of this Agreement. The Schedules may be amended or replaced from time to time by the parties who will evidence their approval thereof by initialing a new Schedule dated as of the effective date of such amendment or replacements.
Amendments and Supplements The Company shall prepare and file with the Commission such amendments, including post-effective amendments, and supplements to such Registration Statement and the prospectus used in connection therewith as may be necessary to keep such Registration Statement effective and in compliance with the provisions of the Securities Act until all Registrable Securities and other securities covered by such Registration Statement have been disposed of in accordance with the intended method(s) of distribution set forth in such Registration Statement or such securities have been withdrawn.
Waiver, Amendments, Etc The Trust shall not waive, modify, amend, supplement or consent to any waiver, modification, amendment of or supplement to, any of the provisions of the Certificate of Trust, the Trust Agreement or any of the other Transaction Documents unless, if no Insurer Default shall have occurred and be continuing, Financial Security shall have consented thereto in writing.
Modifications, Waivers, Amendments and Consents (a) Subject to this Section 3.21, the Servicer may agree to any modification, waiver, forbearance, or amendment of any term of any Mortgage Loan without the consent of the Trustee or any Certificateholder. All modifications, waivers, forbearances or amendments of any Mortgage Loan shall be in writing and shall be consistent with Customary Servicing Procedures. (b) The Servicer shall not agree to enter into, and shall not enter into, any modification, waiver (other than a waiver referred to in Section 3.13, which waiver, if any, shall be governed by Section 3.13), forbearance or amendment of any term of any Mortgage Loan if such modification, waiver, forbearance, or amendment would: (i) affect the amount or timing of any related payment of principal, interest or other amount payable thereunder; (ii) in the Servicer's judgment, materially impair the security for such Mortgage Loan or reduce the likelihood of timely payment of amounts due thereon; or (iii) otherwise constitute a "significant modification" within the meaning of Treasury Regulations Section 1.860G-2(b); unless, in either case, (A) such Mortgage Loan is 90 days or more past due or (B) the Servicer delivers to the Trustee an Opinion of Counsel to the effect that such modification, waiver, forbearance or amendment would not affect the REMIC status of either the Upper-Tier REMIC or the Lower-Tier REMIC and, in either case, such modification, waiver, forbearance or amendment is reasonably likely to produce a greater recovery with respect to such Mortgage Loan than would liquidation. Subject to Customary Servicing Procedures, the Servicer may permit a forbearance for a Mortgage Loan which in the Servicer's judgment is subject to imminent default. (c) Any payment of interest, which is deferred pursuant to any modification, waiver, forbearance or amendment permitted hereunder, shall not, for purposes hereof, including, without limitation, calculating monthly distributions to Certificateholders, be added to the unpaid principal balance of the related Mortgage Loan, notwithstanding that the terms of such Mortgage Loan or such modification, waiver or amendment so permit. (d) The Servicer may, as a condition to granting any request by a Mortgagor for consent, modification, waiver, forbearance or amendment, the granting of which is within the Servicer's discretion pursuant to the Mortgage Loan and is permitted by the terms of this Agreement, require that such Mortgagor pay to the Servicer, as additional servicing compensation, a reasonable or customary fee for the additional services performed in connection with such request, together with any related costs and expenses incurred by the Servicer, which amount shall be retained by the Servicer as additional servicing compensation. (e) The Servicer shall notify the Trustee, in writing, of any modification, waiver, forbearance or amendment of any term of any Mortgage Loan and the date thereof, and shall deliver to the Trustee (or, at the direction of the Trustee, the Custodian) for deposit in the related Mortgage File, an original counterpart of the agreement relating to such modification, waiver, forbearance or amendment, promptly (and in any event within ten Business Days) following the execution thereof; provided, however, that if any such modification, waiver, forbearance or amendment is required by applicable law to be recorded, the Servicer (i) shall deliver to the Trustee a copy thereof and (ii) shall deliver to the Trustee such document, with evidence of notification upon receipt thereof from the public recording office.
Modifications; Amendments; Waivers The terms and provisions of this Agreement may not be modified or amended, nor may any provision be waived, except pursuant to a writing signed by the Corporation and the holders of at least a majority of the Registrable Shares then outstanding.
Waiver; Amendments (a) No failure or delay by the Administrative Agent, the Issuing Bank or any Lender in exercising any right or power hereunder or under any other Loan Document, and no course of dealing between the Borrower and the Administrative Agent or any Lender, shall operate as a waiver thereof, nor shall any single or partial exercise of any such right or power, or any abandonment or discontinuance of steps to enforce such right or power, preclude any other or further exercise thereof or the exercise of any other right or power hereunder or thereunder. The rights and remedies of the Administrative Agent, the Issuing Bank and the Lenders hereunder and under the other Loan Documents are cumulative and are not exclusive of any rights or remedies provided by law. No waiver of any provision of this Agreement or of any other Loan Document or consent to any departure by the Borrower therefrom shall in any event be effective unless the same shall be permitted by subsection (b) of this Section, and then such waiver or consent shall be effective only in the specific instance and for the purpose for which given. Without limiting the generality of the foregoing, the making of a Loan or the issuance of a Letter of Credit shall not be construed as a waiver of any Default or Event of Default, regardless of whether the Administrative Agent, any Lender or the Issuing Bank may have had notice or knowledge of such Default or Event of Default at the time. (b) No amendment or waiver of any provision of this Agreement or of the other Loan Documents, nor consent to any departure by the Borrower therefrom, shall in any event be effective unless the same shall be in writing and signed by the Borrower and the Required Lenders, or the Borrower and the Administrative Agent with the consent of the Required Lenders, and then such amendment, waiver or consent shall be effective only in the specific instance and for the specific purpose for which given; provided that, in addition to the consent of the Required Lenders, no amendment, waiver or consent shall: (i) increase the Commitment of any Lender without the written consent of such Lender; (ii) increase the Borrowing Base without the written consent of each Lender; (iii) modify Section 2.4 in any manner without the consent of each Lender; provided that a Scheduled Redetermination may be postponed by the Required Lenders; (iv) reduce the principal amount of any Loan or LC Disbursement or reduce the rate of interest thereon, or reduce any fees payable hereunder, without the written consent of each Lender entitled to such payment; (v) postpone the date fixed for any payment of any principal of, or interest on, any Loan or LC Disbursement or any fees hereunder or reduce the amount of, waive or excuse any such payment, without the written consent of each Lender entitled to such payment, or postpone the scheduled date for the termination or reduction of the Commitment of any Lender, without the written consent of such Lender; (vi) change Section 2.20(b) or (c) in a manner that would alter the pro rata sharing of payments required thereby, without the written consent of each Lender; (vii) change any of the provisions of this subsection (b) or the definition of “Required Lenders” or any other provision of this Agreement specifying the number or percentage of Lenders which are required to waive, amend or modify any rights hereunder or make any determination or grant any consent hereunder, without the consent of each Lender; (viii) release all or substantially all of the guarantors, or limit the liability of such guarantors, under any guaranty agreement guaranteeing any of the Obligations, without the written consent of each Lender; or (ix) release all or substantially all collateral (if any) securing any of the Obligations, without the written consent of each Lender; provided, further, that no such amendment, waiver or consent shall amend, modify or otherwise affect the rights, duties or obligations of the Administrative Agent or the Issuing Bank without the prior written consent of such Person. Notwithstanding anything to the contrary herein, no Defaulting Lender shall have any right to approve or disapprove any amendment, waiver or consent hereunder, except that the Commitment of such Lender may not be increased or extended, and amounts payable to such Lender hereunder may not be permanently reduced, without the consent of such Lender (other than reductions in fees and interest in which such reduction does not disproportionately affect such Lender). Notwithstanding anything contained herein to the contrary, this Agreement may be amended and restated without the consent of any Lender (but with the consent of the Borrower and the Administrative Agent) if, upon giving effect to such amendment and restatement, such Lender shall no longer be a party to this Agreement (as so amended and restated), the Commitments of such Lender shall have terminated (but such Lender shall continue to be entitled to the benefits of Sections 2.17, 2.18, 2.19 and 10.3), such Lender shall have no other commitment or other obligation hereunder and such Lender shall have been paid in full all principal, interest and other amounts owing to it or accrued for its account under this Agreement.

Permitted Schedule Amendments Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Permitted Schedule Amendments