Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content. For purposes of Sections 2252.152, 2271.002, and 2274.002, Texas Government Code, as amended, C&T hereby verifies that C&T and any parent company, wholly owned subsidiary, majority-owned subsidiary, and affiliate:
a. Unless affirmatively declared by the United States government to be excluded from its federal sanctions regime relating to Sudan or Iran or any federal sanctions regime relating to a foreign terrorist organization, is not identified on a list prepared and maintained by the Texas Comptroller of Public Accounts under Sections 806.051, 807.051, or 2252.153 of the Texas Government Code.
b. If employing ten (10) or more full-time employees and this Agreement has a value of
Training Requirements Grantee shall:
A. Authorize and require staff (including volunteers) to attend training, conferences, and meetings as directed by DSHS;
B. Appropriately budget funds in order to meet training requirements in a timely manner, and ensure that staff and volunteers are trained as specified in the training requirements listed at xxxxx://xxx.xxxx.xxxxx.xxx/hivstd/training/ and as otherwise specified by DSHS. Grantee shall document that these training requirements are met; and
C. Ensure that staff hired for HIV and syphilis testing are trained to perform blood draws within three (3) months of employment.
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day.
B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx.
C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to
D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client.
E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time.
F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx.
G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Use of Subservicers and Subcontractors (a) The Master Servicer shall cause any Subservicer used by the Master Servicer (or by any Subservicer) for the benefit of the Depositor to comply with the provisions of Section 3.16 and this Article XI to the same extent as if such Subservicer were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person). The Master Servicer shall be responsible for obtaining from each Subservicer and delivering to the Depositor any servicer compliance statement required to be delivered by such Subservicer under Section 3.16, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 11.07 and any certification required to be delivered to the Certifying Person under Section 11.05 as and when required to be delivered. As a condition to the succession to any Subservicer as subservicer under this Agreement by any Person (i) into which such Subservicer may be merged or consolidated, or (ii) which may be appointed as a successor to any Subservicer, the Master Servicer shall provide to the Depositor, at least 15 calendar days prior to the effective date of such succession or appointment, (x) written notice to the Depositor of such succession or appointment and (y) in writing and in form and substance reasonably satisfactory to the Depositor, all information reasonably requested by the Depositor in order to comply with its reporting obligation under Item 6.02 of Form 8-K.
(b) It shall not be necessary for the Master Servicer, any Subservicer or the Trustee to seek the consent of the Depositor or any other party hereto to the utilization of any Subcontractor. The Master Servicer or the Trustee, as applicable, shall promptly upon request provide to the Depositor (or any designee of the Depositor, such as the Master Servicer or administrator) a written description (in form and substance satisfactory to the Depositor) of the role and function of each Subcontractor utilized by such Person (or in the case of the Master Servicer or any Subservicer), specifying (i) the identity of each such Subcontractor, (ii) which (if any) of such Subcontractors are "participating in the servicing function" within the meaning of Item 1122 of Regulation AB, and (iii) which elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be a Reporting Subcontractor, the Master Servicer or the Trustee, as applicable, shall cause any such Subcontractor used by such Person (or in the case of the Master Servicer or any Subservicer) for the benefit of the Depositor to comply with the provisions of Sections 11.07 and 11.09 of this Agreement to the same extent as if such Subcontractor were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person) or the Trustee, as applicable. The Master Servicer or the Trustee, as applicable, shall be responsible for obtaining from each Subcontractor and delivering to the Depositor and the Master Servicer, any assessment of compliance and attestation required to be delivered by such Subcontractor under Section 11.05 and Section 11.07, in each case as and when required to be delivered.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Credentialing Requirements Registry Operator, through the facilitation of the CZDA Provider, will request each user to provide it with information sufficient to correctly identify and locate the user. Such user information will include, without limitation, company name, contact name, address, telephone number, facsimile number, email address and IP address.
EDD Independent Contractor Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the state.” The term is further defined by the California Employment Development Department to refer specifically to independent Contractors. An independent Contractor is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Attachment C, Standard State Provisions for Contracts and Grants Attachment C is hereby deleted in its entirety and replaced by the Attachment C December 15, 2017 attached to this Amendment. Child Support (Applicable to natural persons only; not applicable to corporations, partnerships or LLCs). Contractor is under no obligation to pay child support or is in good standing with respect to or in full compliance with a plan to pay any and all child support payable under a support order as of the date of this amendment.
