Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Selection of Architect/Construction Drawings Landlord shall retain, on behalf of Tenant, FPBA Architects (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. Landlord shall retain, on behalf of Tenant, engineering consultants and/or design-build consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing and HYAC work of the Improvements and any relevant components of the Landlord Work. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to Landlord’s approval as more particularly set forth in Sections 3.2 and 3.3, below. Notwithstanding Landlord’s retention of the Architect and Engineers, Tenant shall be responsible for, and shall fully cooperate and coordinate in good faith with Landlord, the Architect and the Engineers to supply all of the necessary information within Tenant’s possession to allow the Architect and the Engineers to initially prepare and then complete, the Construction Drawings. Landlord hereby agrees (at no cost to Landlord) to cooperate, on a commercially reasonable basis, with Tenant to assist Tenant in the preparation of the Construction Drawings. Landlord’s review of the Construction Drawings applicable to the Improvements (as opposed to Landlord Work) and as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Improvement-related portions of such Construction Drawings are reviewed by Landlord, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in such portions of the Construction Drawings, and Tenant’s waiver and indemnity set forth in this Lease shall specifically apply to such portions of the Construction Drawings.
Repair and Replacement Company shall be responsible to Lessor for reasonable replacement costs, or reasonable repair costs of all Equipment which is lost, stolen, or damaged while in the care, custody and control of Company as a result of Company's sole negligence in accordance with paragraph 2 above, reasonable wear and tear excepted, using the Actual Cash Value of the Equipment at the time of such loss. Prior to repairing the Equipment, Lessor shall submit to Company at least three estimates, including at least one estimate from a repair facility designated by Company. In the event the Equipment is lost or stolen, Company shall file a police report.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:
1. Coordination and providing supervision to all Subcontractor and workers;
2. Posting of the prevailing wage scale;
3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel;
4. Conducting weekly on-site safety meetings;
5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day.
a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day.
b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered.
c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation.
6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.
Maintenance Repairs and Alterations 7.1 Lessee's Obligations. --------------------
(a) Subject to Lessor's obligations under Paragraphs 6.2(b), 6.3(a), 7.3, 9 and 40, Lessee shall keep in good order, condition and repair the non- structural elements of the Premises and every part thereof, (whether or not the need for such repairs occurs as a result of Lessee's use, any prior use, the elements or the age of such portion of the Premises) including, without limiting the generality of the foregoing, all exposed plumbing, heating and air conditioning, ventilating, electrical, lighting facilities and equipment within the Premises, fixtures, walls (interior and nonstructural elements of exterior), ceilings, floors, windows, doors, plate glass and skylights located within the Premises, and all driveways, parking lots and striping thereon, landscaping, exterior lighting, fences and signs located on the Premises and sidewalks and parkways adjacent to the Premises. If the cost of repairing an element of the Premises is covered by a warranty obtained by Lessor from a third party contractor, subcontractor, consultant or material supplier in connection with construction work performed on the Premises prior to the Effective Date, Lessor shall make available such warranty to Lessee and shall assign to Lessee Lessor's rights thereunder, provided that Lessee shall not take any action which shall invalidate any such warranty or derogate from Lessor's remedies or recourse thereunder.
(b) Lessee shall maintain the Premises as provided in Paragraph 7. I (a) and in accordance with the requirements of all Laws and any covenants or restrictions as may from time to time be applicable to Lessee's specific manner of use of the Premises and the conduct and operation of Lessee's business. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices and any damage or deterioration shall not be deemed "ordinary wear and tear" if the same could have been prevented by good maintenance practice. Lessee's obligations shall include restorations, replacements or renewals when determined not to be due to ordinary wear and tear or when made necessary due to failure to perform proper maintenance.
(c) If the term of this Lease, as the same may be extended or renewed, exceeds five (5) years, Lessor shall have the right to require Lessee to repaint the exterior of THE improvements. but not more often than once every five (5) years, as reasonably necessary.
(d) Lessee's obligations under this Paragraph 7.1 shall not apply to replacement, repair or restoration of items which are Lessor's obligation to replace, repair or restore pursuant to the terms of Paragraph 6.3(a) (relating to Existing Defects) Paragraph 7.3(a) relating to structural repairs and certain replacements) Paragraph 9 (relating to destruction of the Premises) or Paragraph 14 (relating to condemnation of the Premises).
Mitigation Obligations; Replacement of Lenders (a) If any Lender requests compensation under Section 2.12, or if the Borrower is required to pay any additional amount to any Lender or any Governmental Authority for the account of any Lender pursuant to Section 2.14, then such Lender shall use reasonable efforts to designate a different lending office for funding or booking its Loans hereunder or to assign its rights and obligations hereunder to another of its offices, branches or affiliates, if, in the judgment of such Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 2.12 or 2.14, as the case may be, in the future and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. The Borrower hereby agrees to pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.
(b) If any Lender requests compensation under Section 2.12, or if the Borrower is required to pay any additional amount to any Lender or any Governmental Authority for the account of any Lender pursuant to Section 2.14, or if any Lender defaults in its obligation to fund Loans hereunder, then the Borrower may, at its sole expense and effort, upon notice to such Lender and the Administrative Agent, require such Lender to assign and delegate, without recourse (in accordance with and subject to the restrictions contained in Section 9.04), all its interests, rights and obligations under this Agreement to an assignee that shall assume such obligations (which assignee may be another Lender, if a Lender accepts such assignment); provided that (i) the Borrower shall have received the prior written consent of the Administrative Agent, which consent shall not unreasonably be withheld, (ii) such Lender shall have received payment of an amount equal to the outstanding principal of its Loans, accrued interest thereon, accrued fees and all other amounts payable to it hereunder, from the assignee (to the extent of such outstanding principal and accrued interest and fees) or the Borrower (in the case of all other amounts) and (iii) in the case of any such assignment resulting from a claim for compensation under Section 2.12 or payments required to be made pursuant to Section 2.14, such assignment will result in a reduction in such compensation or payments. A Lender shall not be required to make any such assignment and delegation if, prior thereto, as a result of a waiver by such Lender or otherwise, the circumstances entitling the Borrower to require such assignment and delegation cease to apply.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Additions and Alterations After Substantial Completion of the Facility and Leased Premises, Lessee shall have the right to make, at Lessee’s sole cost and expense, additions, alterations, and changes ("Alterations"), in or to the Leased Premises or the Improvements, provided Lessee shall not then be in default in the performance of any of Lessee's covenants or agreements in this Lease, subject, however, in all cases to the following:
(1) No Alterations of any kind shall be made without the prior written consent of Lessor if the Alterations would tend to: (a) change the general character or structure of the Improvements on the Leased Premises, or (b) reduce or impair the value, rental, rental value, rentability, or usefulness of the Leased Premises or the Improvements or any part of same;
(2) No Alterations shall be undertaken until Lessee shall have procured and paid for, to the extent the same may be required from time to time, all permits and authorizations of all municipal departments and governmental subdivisions having jurisdiction, and complied with all other laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses relating to the Alterations;
(3) Any structural Alterations involving in the aggregate an estimated cost of more than $ shall be conducted under the supervision of an architect or engineer selected by Lessee and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). No such structural Alterations shall be made, except in accordance with detailed plans and specifications and cost estimates prepared and approved in writing by such architect or engineer and approved in advance and in writing by Lessor (which approval shall not be unreasonably withheld or delayed). In the event of Lessor's disapproval, Lessor shall give to Lessee an itemized statement of reasons for the disapproval. If Lessor does not disapprove the plans and specifications provided for in this paragraph within fifteen (15) days after they have been submitted to Lessor, the plans and specifications shall be deemed to have been approved by Lessor. Prior to commencing any work under this Section 11, Lessee shall furnish Lessor, on demand, with a good and sufficient surety bond insuring the completion of the work and the payment of all bills in connection with the work.
(4) Any Alterations shall be made promptly, subject to Force Majeure Delay, and in a good and workmanlike manner and in compliance with all applicable laws, statutes, codes, ordinances, orders, rules, regulations, permits, or licenses, and all insurance policy provisions and requirements;
(5) The cost of any such alterations shall be paid solely by Lessee in cash or its equivalent, including the cost of labor and materials supplied to the Leased Premises or the Improvements;
(6) Workers' compensation insurance covering all persons employed in connection with the Alteration work and with respect to whom death or bodily injury claims could be asserted against Lessor, Lessee, or the Leased Premises or the Improvements, and commercial general liability insurance for the mutual benefit of Lessor and Lessee with limits of not less than $ in the event of bodily injury or death to one person and not less than $ in the event of bodily injury or death to any number of persons in any one accident, and with limits of not less than $ for damages or injury to property, with not more than a $ deductible, shall be maintained by Lessee at Lessee's sole cost and expense at all times when any substantial work is in progress in connection with any Alterations. All such insurance, if readily obtainable, shall be effected under standard form policies issued by insurers of recognized responsibility, which are duly licensed to issue such insurance in the State of Oklahoma and well rated by national rating organizations. SECTION TWELVE INSPECTIONS Lessee shall permit Lessor, Lessor’s agents, employees, and contractors to enter all parts of the Leased Premises and the Improvements during Lessee's regular business hours to inspect the same and to enforce or carry out any provisions of this Lease, provided Lessee is given reasonable advance notice, which may be verbal (except in an emergency, in which case no notice shall be necessary), and Lessee's Permitted Use shall not be unreasonably interfered with by Lessor during any entry authorized in this Section 12.
Mitigation of Obligations Replacement of Lenders (a) If any Lender requests compensation under Section 3.04, or if any Borrower is required to pay any additional amount to any Lender or any Governmental Authority for the account of any Lender pursuant to Section 3.01, then such Lender shall, upon the request of such Borrower, use reasonable efforts to designate a different Lending Office for funding or booking its Loans hereunder or to assign its rights and obligations hereunder to another of its offices, branches or affiliates, if, in the judgment of such Lender, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 3.04 or 3.01, as the case may be, in the future and (ii) would not subject such Lender to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Lender. Each Borrower hereby agrees to pay all reasonable costs and expenses incurred by any Lender in connection with any such designation or assignment.
(b) If a Lender is a Defaulting Lender, or under any circumstances otherwise set forth herein providing that the Borrowers shall have the right to replace a Lender as a party to this Agreement, the Borrowers may, upon notice to such Lender and the Administrative Agent, replace such Lender by causing such Lender to assign its Commitment (with the assignment fee to be paid by the Borrowers in such instance) pursuant to Section 10.07(b) to one or more other Lenders or Eligible Assignees procured by the Borrowers; provided, however, that if the Borrowers elect to exercise such right with respect to any Lender pursuant to Section 3.06(b), it shall be obligated to replace all Lenders that have made requests for compensation on a similar basis and in a similar amount pursuant to Section 3.01 or 3.
