Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:
a) drawings, designs, or specifications, where Goods to be furnished under the Contract are to be specifically manufactured for the Procuring Entity;
b) the method of shipment or packing;
c) the place of delivery; and
d) the Related Services to be provided by the Supplier.
33.2 If any such change causes an increase or decrease in the cost of, or the time required for, the Supplier's performance of any provisions under the Contract, an equitable adjustment shall be made in the Contract Price or in the Delivery/Completion Schedule, or both, and the Contract shall accordingly be amended. Any claims by the Supplier for adjustment under this Clause must be asserted within twenty-eight (28) days from the date of the Supplier's receipt of the Procuring Entity's change order.
33.3 Prices to be charged by the Supplier for any Related Services that might be needed but which were not included in the Contract shall be agreed upon in advance by the parties and shall not exceed the prevailing rates charged to other parties by the Supplier for similar services.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
Standard Contract Attachment C - (Standard Contract Provisions for Contracts and Grants)
Payment and Contract Price C1 Contract Price
C1.1 In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).
C1.2 The Authority shall, in addition to the Contract Price and following evidence of a valid VAT invoice, pay the Contractor a sum equal to the VAT chargeable on the value of the Services supplied in accordance with the Contract. C2 Payment and VAT
C2.1 The Authority shall pay all sums due to the Contractor within thirty (30) days of receipt of a valid invoice, submitted Monthly in arrears.
C2.2 The Authority shall pay all sums by direct credit transfer into a suitable bank account or by other electronic payment methods as appropriate.
C2.3 The Contractor shall ensure that each invoice contains a valid purchase order number. All appropriate references and a detailed breakdown of the Services supplied and any other documentation reasonably required by the Authority to substantiate the invoice should be supplied in accordance with Schedule 2.
C2.4 Where the Contractor enters into a sub-contract for the purpose of performing its obligations under the Contract, it shall ensure that a provision is included in such a sub-contract which requires payment to be made of all sums due by the Contractor to the Sub-contractor within a specified period not exceeding thirty (30) days from the receipt of a valid invoice.
C2.5 The Contractor shall add VAT to the Contract Price at the prevailing rate as applicable and the Authority shall pay the VAT to the Contractor following its receipt of a valid VAT invoice.
C2.6 The Contractor shall indemnify the Authority on a continuing basis against any liability, including any interest, penalties or costs incurred, which is levied, demanded or assessed on the Authority at any time in respect of the Contractor’s failure to account for or to pay any VAT relating to payments made to the Contractor under the Contract. Any amounts due under this clause C2.5 shall be paid by the Contractor to the Authority not less than five (5) Working Days before the date upon which the tax or other liability is payable by the Authority.
C2.7 The Contractor shall not suspend the supply of the Services unless the Contractor is entitled to terminate the Contract under clause H2.3 (Termination on Default) for failure to pay undisputed sums of money. Interest shall be payable by the Authority on the late payment of any undisputed sums of money properly invoiced in accordance with the Late Payment of Commercial Debts (Interest) Xxx 0000.
C2.8 Where payment by the Authority of all or any part of any invoice rendered or other claim for payment by the Contractor is disputed, this dispute shall be resolved in accordance with the disputed claims procedure as set out in Schedule 2. C3 Recovery of Sums Due C3.1 Wherever under the Contract any sum of money is recoverable from or payable by the Contractor (including any sum which the Contractor is liable to pay to the Authority in respect of any breach of the Contract), the Authority may unilaterally deduct that sum from any sum then due, or which at any later time may become due to the Contractor under the Contract or under any other agreement or contract with the Authority. C3.2 Any overpayment by either Party, whether of the Contract Price or of VAT or otherwise, shall be a sum of money recoverable by the Party who made the overpayment from the Party in receipt of the overpayment.
C3.3 The Contractor shall make all payments due to the Authority without any deduction whether by way of set-off, counterclaim, discount, abatement or otherwise unless the Contractor has a valid court order requiring an amount equal to such deduction to be paid by the Authority to the Contractor.
C3.4 All payments due shall be made within a reasonable time unless otherwise specified in the Contract, in cleared funds, to such bank or building society account as the recipient Party may from time to time direct. C4 Price adjustment on extension of the Initial Contract Period
C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Authority agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period), the Authority may, where applicable, in the six (6) Month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than thirty (30) Working Days) to agree a variation in the Contract Price. For the avoidance of doubt both Parties accept and acknowledge that any Variation to the Contract Price shall not have the effect of altering the economic balance of the Contract during the period of extension in favour of the Contractor in a manner not provided for in the terms of the Contract.
C4.2 If the Parties are unable to agree a variation in the Contract Price in accordance with clause C4.1, the Contract shall terminate at the end of the Initial Contract Period.
C4.3 If a variation in the Contract Price is agreed between the Authority and the Contractor, the revised Contract Price will take effect from the first day of any period of extension and shall apply during such period of extension.
C4.4 Any increase in the Contract Price pursuant to clause C4.1 shall not exceed the percentage change in the Office of National Statistics’ Consumer Prices Index (CPI) (or another such index specified in the Prices & Rates Schedule) between the Commencement Date and the date six (6) Months before the end of the Initial Contract Period.] C5 Euro
C5.1 Any requirement of Law to account for the Services in Euro (or to prepare for such accounting) instead of and/or in addition to sterling, shall be implemented by the Contractor at nil charge to the Authority.
C5.2 The Authority shall provide all reasonable assistance to facilitate compliance with clause C5.1 by the Contractor. C6 Third Party Revenue
C6.1 The Contractor may not obtain any third party revenue, income or credit based on the Services and/or copyright works delivered under this Contract without the express prior written agreement of the Authority.
Assignment Amendments Waiver and Contract Complete A. AUDIT.
Term of Contract; Contract Extension The Contract will be in effect from the Effective Date (15 December 2016) through 31 December 2018. DAS, in its sole discretion, may extend this Contract for additional terms beyond the original term, prior to Termination or expiration, one or more times for a combined total period not to exceed the complete length of the original term.
Modifications to Contracts and Credit and Collection Policy Such Seller Party will not make any change to the Credit and Collection Policy that could adversely affect the collectability of the Receivables or decrease the credit quality of any newly created Receivables. Except as provided in Section 8.2(d), Servicer will not extend, amend or otherwise modify the terms of any Receivable or any Contract related thereto other than in accordance with the Credit and Collection Policy.
Attachment C_ CONTRACT AFFIRMATIONS For purposes of these Contract Affirmations, HHS includes both the Health and Human Services Commission (HHSC) and the Department of State Health Services (DSHS). System Agency refers to HHSC, DSHS, or both, that will be a party to this Contract. These Contract Affirmations apply to all Contractors and Grantees (referred to as “Contractor”) regardless of their business form (e.g., individual, partnership, corporation). By entering into this Contract, Contractor affirms, without exception, understands, and agrees to comply with the following items through the life of the Contract:
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.