Post Construction Ownership and Responsibilities
Post Construction Ownership and Responsibilities Sample Clauses
Related to Post Construction Ownership and Responsibilities
Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following: A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. In order to ensure federal funding eligibility, projects must be authorized by the State prior to advertising for construction. B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract. C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting. D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor. E. If the Local Government is the responsible party, the State must review and approve change orders. F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas. G. For federally funded contracts, the parties to this Agreement will comply with federal construction requirements cited in 23 CFR Part 635 and with requirements cited in 23 CFR Part 633, and shall include the latest version of Form “FHWA-1273” in the contract bidding documents. If force account work will be performed, a finding of cost effectiveness shall be made in compliance with 23 CFR 635, Subpart B.
RESTRICTIONS AND RESPONSIBILITIES 2.1 Customer will not, directly or indirectly: reverse engineer, decompile, disassemble or otherwise attempt to discover the source code, object code or underlying structure, ideas, know-how or algorithms relevant to the Services or any software, documentation or data related to the Services (“Software”); modify, translate, or create derivative works based on the Services or any Software (except to the extent expressly permitted by Company or authorized within the Services); use the Services or any Software for timesharing or service bureau purposes or otherwise for the benefit of a third; or remove any proprietary notices or labels. With respect to any Software that is distributed or provided to Customer for use on Customer premises or devices, Company hereby grants Customer a non-exclusive, non-transferable, non-sublicensable license to use such Software during the Term only in connection with the Services. 2.2 Further, Customer may not remove or export from the United States or allow the export or re-export of the Services, Software or anything related thereto, or any direct product thereof in violation of any restrictions, laws or regulations of the United States Department of Commerce, the United States Department of Treasury Office of Foreign Assets Control, or any other United States or foreign agency or authority. As defined in FAR section 2.101, the Software and documentation are “commercial items” and according to DFAR section 252.227-7014(a)(1) and (5) are deemed to be “commercial computer software” and “commercial computer software documentation.” Consistent with DFAR section 227.7202 and FAR section 12.212, any use modification, reproduction, release, performance, display, or disclosure of such commercial software or commercial software documentation by the U.S. Government will be governed solely by the terms of this Agreement and will be prohibited except to the extent expressly permitted by the terms of this Agreement. 2.3 Customer represents, covenants, and warrants that Customer will use the Services only in compliance with Company’s standard published policies then in effect (the “Policy”) and all applicable laws and regulations. Customer hereby agrees to indemnify and hold harmless Company against any damages, losses, liabilities, settlements and expenses (including without limitation costs and attorneys’ fees) in connection with any claim or action that arises from an alleged violation of the foregoing or otherwise from Customer’s use of Services. Although Company has no obligation to monitor Customer’s use of the Services, Company may do so and may prohibit any use of the Services it believes may be (or alleged to be) in violation of the foregoing. 2.4 Customer shall be responsible for obtaining and maintaining any equipment and ancillary services needed to connect to, access or otherwise use the Services, including, without limitation, modems, hardware, servers, software, operating systems, networking, web servers and the like (collectively, “Equipment”). Customer shall also be responsible for maintaining the security of the Equipment, Customer account, passwords (including but not limited to administrative and user passwords) and files, and for all uses of Customer account or the Equipment with or without Customer’s knowledge or consent. 2.5 Customer may opt out of these Terms and Conditions, but doing so will terminate Services.
Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.
Roles and Responsibilities 1. The Donor States shall make funds available in support of eligible programmes proposed by the Beneficiary State and agreed on by the Financial Mechanism Committee within the priority sectors listed in Article 3.1 of Protocol 38c and the programme areas listed in the Annex to Protocol 38c. The Donor States and the Beneficiary State shall cooperate on the preparation of concept notes defining the scope and planned results for each programme. 2. The Beneficiary State shall assure the full co-financing of programmes that benefit from support from the EEA Financial Mechanism 2014-2021 in accordance with Annex B and the programme agreements. 3. The Financial Mechanism Committee shall manage the EEA Financial Mechanism 2014-2021 and take decisions on the granting of financial assistance in accordance with the Regulation. 4. The Committee shall be assisted by the Financial Mechanism Office (hereinafter referred to as the “FMO”). The FMO shall be responsible for the day-to-day operations of the EEA Financial Mechanism 2014-2021 and shall serve as a contact point.
Engineer Responsibilities No subcontract relieves the Engineer of any responsibilities under this contract.
Rights and Responsibilities This Agreement is our standard service agreement. Under this Agreement, we agree to provide and xxxx for Service, and you agree to use and pay for Service, as provided herein and in our other applicable Terms of Service. Our rights and responsibilities, and your rights and responsibilities, are as set forth in this Agreement and our other applicable Terms of Service.
Tenant’s Responsibilities Except as expressly provided in Paragraph 10.1 above, Tenant shall, at its sole cost, maintain the entire Premises and every part thereof, including without limitation, windows, skylights, window frames, plate glass, freight docks, doors and related hardware, interior walls and partitions, and the electrical, plumbing, lighting, heating and air conditioning systems in good order, condition and repair. Tenant shall deliver to Landlord, every six (6) months during the Lease Term, a certificate of maintenance or its equivalent, signed by a licensed HVAC repair and maintenance contractor and stating that the heating and air conditioning systems servicing the Premises have been inspected, serviced and are in good order, condition and repair. Tenant's failure to deliver said certificate or its equivalent within thirty (30) days following written notice from Landlord that said certificate is past due shall be a Default by Tenant. If Tenant fails to make repairs or perform maintenance work required of Tenant hereunder within fifteen (15) days after notice from Landlord specifying the need for such repairs or maintenance work, Landlord or Landlord's agents may, in addition to all other rights and remedies available hereunder or by law and without waiving any alternative remedies, enter into the Premises and make such repairs and/or perform such maintenance work. If Landlord makes such repairs and/or performs such maintenance work, Tenant shall reimburse Landlord upon demand and as Additional Rent, for the cost of such repairs and/or maintenance work. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant or Tenant's agents as a result of Landlord performing any such repairs or maintenance (unless such damage, inconvenience or interference is caused by the gross negligence or willful misconduct of Landlord or its agents, employees or contractors); provided, however, under no circumstances shall Landlord be liable to Tenant for claims of lost profits, loss of business or lost income. Tenant shall reimburse Landlord, on demand and as Additional Rent, for the cost of damage to the Premises and/or Common Area caused by Tenant or Tenant's agents, employees or contractors. Tenant expressly waives the benefits of any statute now or hereafter in effect (including without limitation the provisions of subsection 1 of Section 1932, Section 1941 and Section 1942 of the California Civil Code and any similar law, statute or ordinance now or hereafter in effect) which would otherwise afford Tenant the right to make repairs at Landlord's expense (or to deduct the cost of such repairs from Rentals due hereunder) or to terminate this Lease because of Landlord's failure to keep the Premises in good and sanitary order.
OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Landlord’s Responsibilities (a) Landlord shall correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any non-compliance of the Building exterior and the Common Areas with all applicable building permits and codes in effect as of the Commencement Date, including, without limitation, the provisions of Title III of the Americans With Disabilities Act ("ADA") in effect as of the Commencement Date. Said costs of compliance shall be Landlord's sole cost and shall not be part of Project Costs. Landlord shall correct, repair or replace any non-compliance of the Building exterior and the Common Areas with any revisions or amendments to the ADA in effect after the Commencement Date, provided that the amortized cost of such repairs or replacements (amortized over the useful life thereof using a market cost of funds reasonably determined by Landlord) shall be included as Project Costs payable by Tenant. All other ADA compliance issues which pertain to the Premises, including, without limitation, in connection with Tenant's construction of any alterations or other improvements in the Premises (and any resulting ADA compliance requirements in the Common Areas), the Tenant Improvements and the operation of Tenant's business and employment practices in the Premises, shall be the responsibility of Tenant at its sole cost and expense. Landlord shall, during the initial Lease Term, correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any failure of the structural components of the roof, foundations, footings and load-bearing walls of the Building. The repairs, corrections or replacements required of Landlord or of Tenant under the foregoing provisions of this Section 2.4 shall be made promptly following notice of non-compliance from any applicable governmental agency. (b) Landlord warrants to Tenant that the Shell Building Improvements as defined in the Discovery Outline Specifications (as defined in the Work Letter) and the Tenant Improvements to be completed pursuant to the Work Letter shall be free from defects in workmanship or materials for a period of twelve (12) months from the Commencement Date. Landlord shall promptly rectify any non-compliance at its sole cost and expense after receipt of written notice from Tenant within such time setting forth the nature and extent of any such non-compliance. Landlord shall obtain customary warranties and guaranties from the contractor(s) performing the Tenant Improvement work and/or the manufacturers of equipment installed but shall be under no obligation to incur additional expense in order to obtain or extend such warranties. If after expiration of the initial twelve (12) months of the Lease Term, Tenant is required to make repairs to any component of the Premises or any of its systems for which Landlord may have obtained a warranty, Landlord shall, upon request by Tenant, use its good faith efforts to pursue its rights under any such warranties for the benefit of Tenant. Landlord shall be under no obligation to incur any expense in connection with asserting rights under such warranties or guaranties against either the contractor or the manufacturer, but shall use reasonable good faith efforts to enforce such warranties and guaranties for Tenant's benefit. (c) Notwithstanding the provisions of Section 7.2 of this Lease, Landlord agrees to maintain and repair, at its sole cost and expense and not as an Operating Expense the structural components of the roof and Building, including floor/ceiling slabs, columns, beams, walls and the foundations and footings of the Building during the initial Lease Term. If a non-compliance with the foregoing warranty exists, Landlord shall, promptly after receipt of the written notice from Tenant setting forth the nature and extent of such non-compliance, rectify same at Landlord's sole cost and expense.
