Title Defects 9.1 Purchaser shall have until April 21, 1999 in which to examine the Commitment and the Surveys. If Purchaser finds title to be defective, Purchaser shall, no later than 5:00 p.m. Eastern time on April 21, 1999, notify Seller in writing, specifying the title defect(s). If Purchaser fails to give Seller written notice of any title defect(s) before 5:00 p.m. Eastern time on April 21, 1999, the defects shown in the Commitment or the Surveys shall be deemed to be waived as title objections to closing this transaction.
9.2 If Purchaser has given Seller timely written notice of defect(s) and the defect(s) render the title other than as represented in this Agreement or if any new defects appear from the date of the Commitment through the Closing Date, Seller shall use commercially reasonable efforts to cause only those defects recorded after October 7, 1997 to be cured by the Closing Date. Seller agrees to remove, by payment, bonding or otherwise, any such lien (other than environmental liens) against the Property capable of removal by the payment of money or bonding. Seller shall not be obligated to (but may, in its sole and absolute discretion) cure any other defect or to buyout or settle any other claim or lien against the Property. At Seller's option, the Closing Date may be extended for a period not to exceed sixty (60) days for purposes of eliminating such title defects. If such additional time is reasonably required by Seller to cure such title defects, Seller's failure to extend the Closing Date shall be commercially unreasonable.
9.3 If Seller does not eliminate such defects as of the Closing Date, as the same may be extended under the preceding sentence, or if any new "title defects" appear between the date of the Commitment through the Closing Date which Seller does not eliminate as of the Closing Date, Purchaser shall have the option to:
9.3.1 Close and accept the title "as is," without reduction in the Purchase Price and without claim against Seller for such title defects (except for any lien that Seller is required to cure pursuant to Section 9.2 that can be removed by the payment of money or bonding, for which credit shall be given Purchaser at the Closing unless Seller pays the same at the Closing) (and in such event, the Closing shall take place on the Closing Date); or
9.3.2 Cancel this Agreement, whereupon Escrow Agent, subject to the provisions of Section 11.3, shall return the Deposit, together with all interest earned thereon, to Purchaser, and both parties shall be released from all further obligations under this Agreement, except for those which expressly survive such termination, unless such title defects were caused by Seller's willful act or willful omission, in which event Seller shall remain liable to Purchaser for damages caused by such title defects.
Environmental Defects If Buyer determines that with respect to the Asset there exists an Environmental Condition (other than with respect to asbestos, asbestos containing materials, or NORM, and excluding any matter set forth on Schedule 6.10) (in each case, an “Environmental Defect”), then on or prior to the Defect Claim Date, Buyer may give Seller a written notice of such Environmental Defect that sets forth the information required by this Section 3.17 (an “Environmental Defect Notice”). For all purposes of this Agreement and notwithstanding anything herein to the contrary, Buyer shall be deemed to have waived any Environmental Defect that Buyer fails to timely and properly assert as an Environmental Defect by an Environmental Defect Notice received by Seller on or before the Defect Claim Date. To be effective, an Environmental Defect Notice must set forth (a) a clear description of the matter constituting the alleged Environmental Defect, (b) a description of each Asset (or portion thereof) affected by the alleged Environmental Defect, (c) the estimated proportionate share attributable to the Assets of the estimated Lowest Cost Response to eliminate the alleged Environmental Defect (the “Environmental Defect Amount”), and (d) supporting documents and reasonably necessary for Seller to verify the existence of the alleged Environmental Defect and the Environmental Defect Amount. Buyer shall furnish Seller, on or before the end of each calendar week prior to the Defect Claim Date, Environmental Defect Notices with respect to any Environmental Defects that any of Buyer’s or any of its Affiliate’s employees, representatives, attorneys, or other environmental personnel or contractors discover or become aware of during the preceding calendar week, which notice may be preliminary in nature and supplemented prior to the Defect Claim Date; provided that notwithstanding this sentence, any Environmental Defect Notice shall be deemed timely if received by Seller prior to the Defect Claim Date.
Title Defect (a) In the event Seller receives notice of any Survey Objection or Title Objection (collectively and individually a “Title Defect”) within the time periods required under Sections 6.1 and 6.2 above, Seller may elect (but shall not be obligated) to attempt to remove, or cause to be removed at its expense, any such Title Defect, and shall provide Purchaser with notice within five (5) days of its receipt of any such objection, of its intention to attempt to cure such any such Title Defect. If Seller elects to attempt to cure any Title Defect, the Scheduled Closing Date shall be extended for a period of twenty (20) days for the purpose of such removal. In the event that (i) Seller elects not to attempt to cure any such Title Defect, or (ii) Seller is unable to cure any such Title Defect within such twenty (20) days from the Scheduled Closing Date, Seller shall so notify Purchaser and Purchaser shall have the right to terminate this Agreement pursuant to this Section 6.3(a) and receive a refund of the Xxxxxxx Money Deposit, together with all interest which has accrued thereon, or to waive such Title Defect and proceed to the Closing. Purchaser shall make such election by written notice to Seller within three (3) days after receipt of Seller’s notice. If Seller has elected to cure a Title Defect and thereafter fails to timely cure such Title Defect, and Purchaser elects to terminate this Agreement, then (i) Seller shall reimburse Purchaser for its reasonable out-of-pocket costs and expenses payable to third parties in connection with this transaction incurred after the date on which Seller informed Purchaser of its election to cure the Title Defect, not to exceed the Reimbursement Cap, and (ii) Purchaser shall promptly return Purchaser’s Information to Seller, after which neither party shall have any further obligation to the other under this Agreement except for the Termination Surviving Obligations. If Purchaser elects to proceed to the Closing, any Title Defects waived by Purchaser shall be deemed to constitute Permitted Exceptions, and there shall be no reduction in the Purchase Price. If, within the three-day period, Purchaser fails to notify Seller of Purchaser’s election to terminate, then Purchaser shall be deemed to have waived the Title Defect and to have elected to proceed to the Closing.
(b) Notwithstanding any provision of this Article VI to the contrary, Seller shall be obligated to cure exceptions to title to the Property, in the manner described above, relating to liens and security interests securing any financings to Seller, any judgment liens, which are in existence on the Effective Date, or which come into existence after the Effective Date, and any mechanic’s liens resulting from work at the Property commissioned by Seller; provided, however, that any such mechanic’s lien may be cured by bonding in accordance with Pennsylvania law. In addition, Seller shall be obligated to pay off any outstanding real estate taxes that were due and payable prior to the Closing (but subject to adjustment in accordance with Section 10.4 below).
Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing.
(b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD.
(c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article.
(d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.
35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
Notice of Title Defects (a) If Buyer discovers any Title Defect affecting any Asset, Buyer shall notify Seller as promptly as possible, but no later than the expiration of the Examination Period of such alleged Title Defect. To be effective, such notice must (i) be in writing, (ii) be received by Seller by 5:00 p.m. Central Standard Time on the expiration date of the Examination Period and (iii) describe the Title Defect in reasonable detail, to the extent then reasonably known by Buyer (including the estimated value of such Title Defect as determined by Buyer). Any matters that may otherwise constitute Title Defects, but of which Seller has not been notified by Buyer in accordance with the foregoing, shall be deemed to have been waived by Buyer for all purposes and shall constitute Permitted Encumbrances.
(b) Upon the receipt of such effective notice from Buyer, Seller, at Seller’s option, shall (i) subject to Section 3.05(a), attempt to cure such Title Defect at any time prior to the Closing or (ii) exclude the affected Asset from the sale and reduce the Purchase Price by the Allocated Value of such affected Asset as set forth on Exhibit C.
(c) The value attributable to each Title Defect (the “Title Defect Value”) that is asserted by Buyer in the Title Defect notices shall be determined based upon the criteria set forth below:
(i) If the Title Defect is a lien upon any Asset, the Title Defect Value is the amount reasonably expected to be necessary to be paid to remove the lien from the affected Asset.
(ii) If the Title Defect asserted is that the Net Revenue Interest attributable to any Well or unit or Well location is less than that stated in Exhibit C or the Working Interest attributable to any Well or unit or Well location is greater than that stated in Exhibit C, then the Title Defect Value shall take into account the relative change in the interest from Exhibit C and the appropriate Allocated Value attributed to such Asset.
(iii) If the Title Defect represents an obligation, encumbrance, burden or charge upon the affected Asset (including any increase in Working Interest for which there is not a proportionate increase in Net Revenue Interest) for which the economic detriment to Buyer is unliquidated, the amount of the Title Defect Value shall be determined by taking into account the Allocated Value of the affected Asset, the portion of the Asset affected by the Title Defect, the legal effect of the Title Defect, the potential discounted economic effect of the Title Defect over the life of the affected Asset.
(iv) If a Title Defect is not in effect or does not adversely affect an Asset throughout the entire productive life of such Asset, such fact shall be taken into account in determining the Title Defect Value.
(v) The Title Defect Value shall be determined without duplication of any costs or losses included in another Title Defect Value hereunder.
(vi) Notwithstanding anything herein to the contrary, in no event shall a Title Defect Value exceed the Allocated Value of the Wxxxx, units or other Assets affected thereby.
(vii) Such other factors as are reasonably necessary to make a proper evaluation.
Remedies for Title Defects (a) With respect to each Title Defect that Seller does not cure on or before the Closing, except as otherwise provided in this Section 3.05, the Purchase Price shall be reduced by an amount equal to the Title Defect Value agreed upon in writing by Buyer and Seller or, if Buyer agrees, Seller shall indemnify Buyer pursuant to Section 14.04 against all costs which Buyer may incur in connection with such Title Defect. If any Title Defect is in the nature of an unobtained consent to assignment or other restriction on assignability, the provisions of Section 3.08 shall apply.
(b) Except for those affected Assets which Seller elects to exclude from this transaction pursuant to Section 3.04(b)(ii), if on or before Closing the Parties have not agreed upon the validity of any asserted Title Defect or have not agreed on the Title Defect Value attributable thereto, either Party shall have the right to elect to have the validity of such Title Defect and/or such Title Defect Value determined by an Independent Expert pursuant to Section 16.03; provided that if the validity of any asserted Title Defect, or the Title Defect Value attributable thereto, is not determined before Closing, the affected Asset shall be excluded from the sale and the Purchase Price shall be reduced by the Allocated Value of such affected Asset as set forth on Exhibit C. Upon resolution of such dispute, the Allocated Value of that Asset less the Title Defect Value, if any, found to be attributable to such Title Defect shall, subject to this Section 3.05, be paid by Buyer to Seller and the Asset conveyed to Buyer, if that is part of the mutually agreed settlement.
(c) Notwithstanding anything to the contrary in this Agreement, (i) if the value of a given individual Title Defect (or individual Title Benefit (as defined in Section 3.09(a)) does not exceed $50,000 then no adjustment to the Purchase Price shall be made for such Title Defect (or Title Benefit), (ii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects (as hereinafter defined) does not exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then no adjustment of the Purchase Price shall be made therefor and (iii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then the Purchase Price shall only be adjusted by the amount of such excess.
Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to:
(a) the design of the Project;
(b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards;
(c) improper maintenance during construction of the Project Highway by the Contractor; and/ or
(d) failure by the Contractor to comply with any other obligation under this Agreement.
Remedies for Environmental Defects (a) If any Environmental Defect described in a notice delivered in accordance with Section 4.03 is not cured on or before the Closing, and Seller has not elected to exclude the affected Assets from this sale or Buyer and Seller have not agreed for Seller to indemnify Buyer for the Environmental Defect, then the Purchase Price shall be reduced by the Environmental Defect Value of such Environmental Defect as agreed by the Parties.
(b) If Buyer and Seller have not agreed as to the validity of any asserted Environmental Defect, or if the Parties have not agreed on the Environmental Defect Value therefor, and if Seller shall not have elected to exclude the affected Assets from this sale pursuant to Section 4.03(b)(ii), then either Party shall have the right to elect to have the validity of the asserted Environmental Defect, and/or the Environmental Defect Value for such Environmental Defect, determined by an Independent Expert pursuant to Section 16.03. If the validity of any such asserted Environmental Defect or the amount of any such Environmental Defect Value is not determined by the Closing, the Asset affected by such disputed Environmental Defect shall be excluded from the Closing and the Purchase Price paid at the Closing shall be reduced by the Allocated Value of that Asset. Upon resolution of such dispute, the Allocated Value of that Asset less the Environmental Defect Value, if any, found to be attributable to such Environmental Defect shall, subject to this Section 4.04, be paid by Buyer to Seller and the Asset conveyed to Buyer, if that is part of the mutually agreed settlement. Notwithstanding the foregoing, either Buyer or Seller shall have the right to exclude an Asset from the sale if the Environmental Defect Value exceeds the Allocated Value of the Asset(s) affected thereby.
(c) Notwithstanding anything to the contrary in this Agreement, (i) if the Environmental Defect Value for a given individual Environmental Defect does not exceed $50,000, then no adjustment to the Purchase Price shall be made for such Environmental Defect; (ii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does not exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then no adjustment of the Purchase Price shall be made therefore and (iii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then the Purchase Price shall only be adjusted by the amount of such excess.
