Settlement Amount If the Non-Defaulting Party has declared an Early Termination Date pursuant to Section 7.2(b), the Non-Defaulting Party shall have the right to (i) accelerate all amounts owing between the Defaulting Party and the Non-Defaulting Party and to liquidate and terminate the undertakings set forth in this Agreement as between the Defaulting Party and the Non-Defaulting Party; and (ii) withhold any payments due to the Defaulting Party under this Agreement pending payment of the Termination Payment. The Non-Defaulting Party will calculate, in a commercially reasonable manner, the Settlement Amount with respect to the Defaulting Party’s obligations under the Agreement and shall net the Settlement Amount in the manner provided for in Section 7.3(c).
Gross Settlement Amount Except as otherwise provided by Paragraph 9 below, Defendant promises to pay $195,000.00 and no more as the Gross Settlement Amount and to separately pay any and all employer payroll taxes owed on the Wage Portions of the Individual Class Payments. Defendant has no obligation to pay the Gross Settlement Amount (or any payroll taxes) prior to the deadline stated in Paragraph 6.1 of this Agreement. The Administrator will disburse the entire Gross Settlement Amount without asking or requiring Participating Class Members or Aggrieved Employees to submit any claim as a condition of payment. None of the Gross Settlement Amount will revert to Defendant.
Funding of Gross Settlement Amount Defendant shall fully fund the Gross Settlement Amount, and also fund the amounts necessary to fully pay Defendant’s share of payroll taxes by transmitting the funds to the Administrator no later than 30 days after the Effective Date.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Payments from the Gross Settlement Amount The Administrator will make and deduct the following payments from the Gross Settlement Amount, in the amounts specified by the Court in the Final Approval:
Average Contribution Amount For purposes of this Agreement, to ensure that all employees enrolled in health insurance through the City’s HSS are making premium contributions under the Percentage-Based Contribution Model, and therefore have a stake in controlling the long term growth in health insurance costs, it is agreed that, to the extent the City's health insurance premium contribution under the Percentage-Based Contribution Model is less than the “average contribution,” as established under Charter section A8.428(b), then, in addition to the City’s contribution, payments toward the balance of the health insurance premium under the Percentage-Based Contribution Model shall be deemed to apply to the annual “average contribution.” The parties intend that the City’s contribution toward employee health insurance premiums will not exceed the amount established under the Percentage-Based Contribution Model.
Reallocation to a Class with a Lower Salary Range Maximum 1. If the employee meets the skills and abilities requirements of the position and chooses to remain in the reallocated position, the employee retains existing appointment status and has the right to be placed on the Employer’s internal layoff list for the classification occupied prior to the reallocation.
MEASUREMENT AND PAYMENT Temporary traffic control work, including, but not limited to installation and removal of portable signs, cones, drums, skinny drums, flaggers, AFAD’s, changeable message boards, truck mounted attenuators, flashing arrow boards, and pilot vehicles will be paid at the contract lump sum price for
