Price Relief for Owner-Caused Delay. The Owner shall pay the Design- Builder its reasonable Cost Substantiated costs incurred due to an Owner-directed delay in the commencement of the Acceptance Tests.
Price Relief for Owner-Caused Delay Sample Clauses
Related to Price Relief for Owner-Caused Delay
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Termination for fault 19.3.1 The Commonwealth may terminate this Agreement by notice where the Grantee has: (a) failed to comply with an obligation under this Agreement and the Commonwealth believes that the non‐compliance is incapable of remedy or where clause 19.2.2(b) applies; (b) provided false or misleading statements in relation to the Grant; or (c) become bankrupt or insolvent, entered into a scheme of arrangement with creditors, or come under any form of external administration. 19.3.2 The Grantee agrees, on receipt of the notice of termination, to: (a) stop the performance of the Grantee’s obligations; (b) take all available steps to minimise loss resulting from the termination; and (c) report on, and return any part of the Grant to the Commonwealth, or otherwise deal with the Grant, as directed by the Commonwealth.
SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.
Erroneous Termination for Default If, after notice of termination of Vendor’s right to proceed under the provisions of this clause, it is determined for any reason that the contract was not in default, or that the delay was excusable under the provisions of the prior paragraph (Excuse for Nonperformance or Delayed Performance), the rights and obligations of the parties shall be the same as if the notice of termination had been one of termination for convenience.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
