Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Claims-made limitations The following provisions shall apply if the professional liability coverage is written on a claims-made form:
Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement.
NO EXTRA CLAIMS The Employees and the Union shall not pursue any extra claims, either Award or over Award for the life of the Agreement. Without limiting the generality of the foregoing, there shall be no industrial action for the purpose of supporting or advancing claims against the company in relation to the above, until the Agreement's nominal expiry date has passed. Where any disagreement arises, the parties shall follow the Dispute Settlement Procedure contained in this Agreement.
Claims A. To accept HHSC's reimbursement rates as payment in full for the services specified in this Contract to the persons for whom a payment is received, and to make no additional charge to the individual, any member of their family or to any other source for any supplementation for such services, unless specifically allowed by HHSC rules.
Employer Liability 45.1 The Employer shall indemnify and save harmless all Employees from legal liability and all actions, causes of action, claims or demands whatsoever arising out of any occurrence occurring during the course of or performed pursuant to and within the scope of their employment, save and except in the case of gross negligence or wilful misconduct, provided timely notice is given to the Employer of any occurrence giving rise or likely to give rise to a claim against a member of the Employer.
