Abuse and Neglect of Children and Vulnerable Adults:
Abuse Registry Party agrees not to employ any individual, to use any volunteer or other service provider, or to otherwise provide reimbursement to any individual who in the performance of services connected with this agreement provides care, custody, treatment, transportation, or supervision to children or to vulnerable adults if there has been a substantiation of abuse or neglect or exploitation involving that individual. Party is responsible for confirming as to each individual having such contact with children or vulnerable adults the non-existence of a substantiated allegation of abuse, neglect or exploitation by verifying that fact though (a) as to vulnerable adults, the Adult Abuse Registry maintained by the Department of Disabilities, Aging and Independent Living and (b) as to children, the Central Child Protection Registry (unless the Party holds a valid child care license or registration from the Division of Child Development, Department for Children and Families). See 33 V.S.A. §4919(a)(3) and 33 V.S.A. §6911(c)(3).
Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement:
A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced.
B. The use of tobacco or tobacco products on Board property is prohibited by State law.
C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond.
D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others.
E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement.
F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District.
G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.
Contract for Professional Services of Physicians Optometrists, and Registered Nurses
Technical and Organizational Measures The following sections define SAP’s current technical and organizational measures. SAP may change these at any time without notice so long as it maintains a comparable or better level of security. Individual measures may be replaced by new measures that serve the same purpose without diminishing the security level protecting Personal Data.
Sub-Advisor Compliance Policies and Procedures The Sub-Advisor shall promptly provide the Trust CCO with copies of: (i) the Sub-Advisor’s policies and procedures for compliance by the Sub-Advisor with the Federal Securities Laws (together, the “Sub-Advisor Compliance Procedures”), and (ii) any material changes to the Sub-Advisor Compliance Procedures. The Sub-Advisor shall cooperate fully with the Trust CCO so as to facilitate the Trust CCO’s performance of the Trust CCO’s responsibilities under Rule 38a-1 to review, evaluate and report to the Trust’s Board of Trustees on the operation of the Sub-Advisor Compliance Procedures, and shall promptly report to the Trust CCO any Material Compliance Matter arising under the Sub-Advisor Compliance Procedures involving the Sub-Advisor Assets. The Sub-Advisor shall provide to the Trust CCO: (i) quarterly reports confirming the Sub-Advisor’s compliance with the Sub-Advisor Compliance Procedures in managing the Sub-Advisor Assets, and (ii) certifications that there were no Material Compliance Matters involving the Sub-Advisor that arose under the Sub-Advisor Compliance Procedures that affected the Sub-Advisor Assets. At least annually, the Sub-Advisor shall provide a certification to the Trust CCO to the effect that the Sub-Advisor has in place and has implemented policies and procedures that are reasonably designed to ensure compliance by the Sub-Advisor with the Federal Securities Laws.
Conflict of Interest Contractor Personnel 2.5.1 The A-E shall exercise reasonable care and diligence to prevent any actions or conditions that could result in a conflict with the best interests of the COUNTY. This obligation shall apply to the A-E; the A-E’s employees, agents, and relatives; sub-tier contractors; and third parties associated with accomplishing work and PROJECTS/SERVICES hereunder.
2.5.2 A-E’s efforts shall include, but not be limited to establishing precautions to prevent its employees or agents from: making, receiving, providing or offering gifts, entertainment, payments, loans or other considerations which could be deemed to appear to influence individuals to act contrary to the best interests of the COUNTY.
Technical and Organisational Measures (1) Before the commencement of processing, the Supplier shall document the execution of the necessary Technical and Organisational Measures, set out in advance of the awarding of the Order or Contract, specifically with regard to the detailed execution of the contract, and shall present these documented measures to the Client for inspection. Upon acceptance by the Client, the documented measures become the foundation of the contract. Insofar as the inspection/audit by the Client shows the need for amendments, such amendments shall be implemented by mutual agreement.
(2) The Supplier shall establish the security in accordance with Article 28 Paragraph 3 Point c, and Article 32 GDPR in particular in conjunction with Article 5 Paragraph 1, and Paragraph 2 GDPR. The measures to be taken are measures of data security and measures that guarantee a protection level appropriate to the risk concerning confidentiality, integrity, availability and resilience of the systems. The state of the art, implementation costs, the nature, scope and purposes of processing as well as the probability of occurrence and the severity of the risk to the rights and freedoms of natural persons within the meaning of Article 32 Paragraph 1 GDPR must be taken into account. [Details in Appendix 1]
(3) The Technical and Organisational Measures are subject to technical progress and further development. In this respect, it is permissible for the Supplier to implement alternative adequate measures. In so doing, the security level of the defined measures must not be reduced. Substantial changes must be documented.
PROFESSIONAL GRIEVANCE PROCEDURE A. Any claim by the Association or a teacher that there has been a violation, misinterpretation, or misapplication of the terms of the Agreement or violation of any established policy shall be a grievance and shall be resolved through the procedure set forth herein.
B. In the event that a teacher, or the Association believes there is a basis for a grievance, the teacher or representative of the Association within thirty (30) working days of the time the teacher knew of the circumstances giving rise to the grievance, shall first discuss the alleged grievance with the building principal either personally or accompanied by the Association Representative. The grievance process may begin at the Superintendent’s level when the building principal is not involved with an alleged incident.
C. If, as a result of the informal discussion with the building principal, a grievance still exists, the teacher or representative of the Association may, within ten (10) working days, invoke the formal grievance procedure through the Association on the grievance report form, signed by the grievant and a representative of the Association. Said form shall be available from the Association Representative in each building. A copy of the grievance form shall be delivered to the building principal, it may be filed with the Superintendent or a representative designated by him.
D. Within five (5) working days of receipt of the grievance the principal shall meet with the Association in an effort to resolve the grievance. The principal shall indicate his/her disposition of the grievance in writing within five (5) working days of such meeting and shall furnish a copy thereof to the Association. If the Association desires to proceed to the next step, it shall do so within fifteen (15) calendar days of the principal’s disposition.
E. If the Association is not satisfied with the disposition of the grievance, or if no disposition has been made within five (5) working days of such meeting (or ten [10] working days from the date of filing, whichever shall be later) the grievance shall be transmitted to the Superintendent. Within seven (7) working days the Superintendent or his/her designee, shall meet with the Association concerning the grievance and shall indicate his/her disposition of the grievance in writing within five (5) working days of such meeting, and shall furnish a copy thereof to the Association.
F. If the Association is not satisfied with the disposition of the superintendent, or if no disposition has been received within five (5) working days of such meeting the Association may proceed to a Board Level Hearing. This grievance hearing shall be heard in closed session, so long as it does not violate the open meetings act. If the grievance is not settled at the preceding step, it may be submitted to binding arbitration. Within fifteen (15) working days of the receipt of the Superintendent’s answer, the party choosing to arbitrate must give written notice to the other party, setting forth specifically the nature of the dispute to be arbitrated. The charging party shall file a Demand for Arbitration with the American Arbitration Association within fifteen (15) days from the notification date that arbitration will be pursued. The arbitrator shall be selected by the American Arbitration Association in accordance with its rules, which shall likewise govern the arbitration proceedings.
G. The arbitrator shall have no power to rule on any of the following:
1. The termination of services of or failure to re-employ any probationary teacher.
2. Any claim or complaint for which there is another remedial procedure or forum established by law or by regulation having the force of law, including any matter subject to the procedures specified in the Teacher’s Tenure Act (Act IV Public Acts, Extra Session of 1937 of Michigan, as amended).
3. Any matter involving the content of a teacher evaluation.
H. The Board and the Association shall not be permitted to assert in such arbitration proceedings any ground or to rely on any evidence not previously disclosed to the other party. The arbitrator shall have no power to alter, add to, or subtract from the terms of this Agreement. Both parties agree to be bound by the decision of the arbitrator and agree that judgment thereon may be entered in any court of competent jurisdiction.
I. The fees and expense of the arbitrator shall be shared equally by both parties.
J. The time limits provided in this Article shall be strictly observed but may be extended by written agreement of the parties. In the event a grievance is filed after May 15 of any year and strict adherence to the time limits may result in hardship to any party, the Board shall use its best efforts to process such grievance prior to the end of the school term or as soon thereafter as possible.
Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.
Credentialing Firm shall be required to access Citizens’ online vendor credentialing system (“CAIS”) to input, update and maintain certain information about Firm and the persons who will perform work related to this Agreement (“Staff”), as provided below and in Exhibit B attached hereto.
