Procedures for Approval Sample Clauses
The Procedures for Approval clause outlines the specific steps and requirements that must be followed to obtain necessary consents or authorizations under an agreement. Typically, this clause details who must provide approval, the method for submitting requests (such as in writing or via a designated platform), and any timeframes or documentation required for the approval process. By establishing a clear and consistent process, this clause helps prevent misunderstandings and delays, ensuring that all parties know how and when approvals must be sought and granted.
Procedures for Approval a. Prior notice to and authorization by the principal is required for absences due to the reasons stated above except the employee shall give notice to the principal as soon as possible in regard to Section 1, and 4 above.
b. All applications for excusable absences within the provisions of this Article, shall be forwarded to the Personnel Board with the principal's approval or disapproval indicated thereon.
Procedures for Approval a. Prior notice to and authorization by the Chief Executive Officer or designee of the Office of School Food are required for absences due to the reasons stated above except the employee shall give notice to the Chief Executive Officer or designee of the Office of School Food as soon as possible in regard to Section 1 and 4 above.
b. All applications for excusable absences within the provisions of this Article, shall be forwarded to the Personnel Board with the Administrator of the Office of School Food Services' approval or disapproval indicated thereon.
Procedures for Approval. 1. Tenant shall submit to the Landlord and the Building manager a request to perform the work. The request shall include the following enclosures:
(i) A list of Tenant’s proposed contractors and/or subcontractors for Landlord’s approval.
(ii) Four complete sets of plans and specifications properly stamped by a registered architect and/or professional engineer.
(iii) A properly executed application form of Alteration form as may be required by the Town of Hempstead and/or other agencies having jurisdiction.
(iv) Four executed copies of the Insurance Requirements agreement in the form attached to these Rules and Regulations from Tenant’s contractor and from the contractor’s subcontractors.
(v) Contractor’s and subcontractor’s insurance certificates including a “hold harmless” in accordance with the Insurance Requirements agreement.
2. If Alterations are generally acceptable and otherwise permitted by the Lease, Landlord will return the following to Tenant:
(i) Plans approved or returned with comments (such approval or comments shall not constitute a waiver of Department of Buildings approval or approval of other jurisdictional agencies).
(ii) Signed application forms referred to in B1(iii) above, providing proper submissions have been made.
(iii) Two fully executed copies of the Insurance Requirements agreement.
(iv) Covering transmittal letter.
3. Tenant shall obtain Department of Buildings approval of plans and a permit from the Department of Buildings and/or other agencies having jurisdiction. Tenant shall be responsible for keeping current all permits.
Procedures for Approval. 1. Tenant shall submit to the Landlord and the Building Manager a request to perform the work. The request shall include the following enclosures:
(i) A list of Tenant's proposed contractors and/or subcontractors for Landlord's approval, which shall not be unreasonably withheld, conditioned or delayed.
(ii) Four complete sets of plans and specifications properly stamped by a registered architect and/or professional engineer.
(iii) A properly executed application form or Alteration form as may be required by the Township of Piscataway and/or other agencies having jurisdiction.
(iv) Four executed copies of the Insurance Requirements agreement in the form attached to these Rules and Regulations from Tenant's contractor and from the contractor's subcontractors.
(v) Contractor's and subcontractor's insurance certificates including a "hold harmless" in accordance with the Insurance Requirements agreement.
2. If alterations are generally acceptable and otherwise permitted by the Lease, within ten (10) business days, Landlord will return the following to Tenant:
(i) Plans approved or returned with comments (such approval or comments shall not constitute a waiver of Department of Buildings approval or approval of other jurisdictional agencies).
(ii) Signed application forms referred to in B.(iii) above, providing proper submissions have been made.
(iii) Two fully executed copies of the Insurance Requirements agreement.
Procedures for Approval. Field review the proposed adjustment with the utility company.
Procedures for Approval. As part of this Agreement, the Parties agree to the following procedures for obtaining preliminary court approval of this Agreement, notifying members of the Plaintiff Class, submitting objections to the final settlement, and obtaining final court approval of the Final Judgment:
Procedures for Approval. The approval procedure is identical for the fast process agreements project related with the following exceptions: