Product Technical Complaints Recalls Returns Sample Clauses

Open Split View

Download

Share

Cite

Product Technical Complaints Recalls Returns 

Sample 1Sample 2

Save

Copy

Related to Product Technical Complaints Recalls Returns

• Product Complaints Subdistributor shall promptly notify Distributor of (but in no event later than 24 hours after receipt), and provide, upon Distributor’s request, reasonable assistance to address and investigate, any complaint or adverse claim about any Product or its use of which Subdistributor becomes aware;

• Product Recalls (a) If either Party reasonably decides or is required by any government authority or court of competent jurisdiction, to initiate a product recall, withdrawal or field correction with respect to, or if there is any governmental seizure of, the Product, the Party initiating or required to initiate such action will notify the other Party promptly of the details regarding such action, including providing copies of all relevant documentation concerning such action. The Parties will assist each other in investigating any such situation and all regulatory contacts that are made and all activities concerning seizure, recall, withdrawal or field correction will be jointly coordinated by HSL and LMI. (b) If any such recall, withdrawal, field correction or seizure occurs due solely to (i) failure of any Product produced by HSL hereunder to conform to Specifications (including, without limitation, being adulterated or misbranded) or any warranty or other requirement set forth in this Agreement, (ii) the failure of HSL to comply in all material respects with any applicable law, rule, regulation, guideline, standard, court order or decree or (iii) the negligent or intentional wrongful act or omission of HSL in connection with the production of Product hereunder, then HSL shall bear the **** of any such seizure, recall, withdrawal or field correction and shall reimburse LMI for its ****, including any purchase price payments made to HSL and related taxes to the extent related to such recalled Product. To the extent any such recall, withdrawal, field correction or seizure occurs for any reason other than that set forth in the immediately preceding sentence, then LMI shall bear the **** of any such seizure, recall, withdrawal or field correction. If both HSL and LMI contribute to the cause of a seizure, recall, withdrawal or field correction, the cost and expense thereof will be shared in proportion to each Party’s contribution to the problem. For the purposes of this Agreement, the expenses of any recall, withdrawal, field correction or seizure shall include, without limitation, the out-of-pocket expenses of notification and destruction or return of the recalled Product and all other out-of-pocket costs incurred in connection with such recall but shall not include a Party’s lost profits. HSL’s reimbursement for the costs of LMI Materials related to such recall, withdrawal or field correction is limited by Section 5.6(c).

• Product Claims The parties acknowledge that NCR Voyix, not Apple, is responsible for addressing any claims you or any third party relating to the Software or your possession and/or use of the Software, including, but not limited to: (a) product liability claims; (b) any claim that the Software fails to conform to any applicable legal or regulatory requirement; and (c) claims arising under consumer protection or similar legislation.

• Product Returns Client will have the responsibility for handling customer returns of the Products. Patheon will give Client any assistance that Client may reasonably require to handle the returns.

• Customer Complaints Each party hereby agrees to promptly provide to the other party copies of any written or otherwise documented complaints from customers of Dealer received by such party relating in any way to the Offering (including, but not limited to, the manner in which the Shares are offered by the Dealer Manager or Dealer), the Shares or the Company.

• Product Recall (a) If a recall is required by applicable Law, or if Buyer or Supplier reasonably determines that a recall is advisable because the goods may create a potential safety hazard, are not in compliance with any applicable code, standard or legal requirement, or contain a defect or non-conformance with the requirements of this Order occurring or likely to occur in multiple goods, which such defects or non-conformances are substantially similar or have substantially similar causes or effects (collectively a “Serial Defect”), the parties shall promptly communicate such facts to each other. At Buyer’s request, Supplier shall promptly develop a corrective action plan satisfactory to Buyer, which shall include all actions required to recall and/or repair the goods and any actions required by applicable Law (“Corrective Action Plan”) for Buyer’s review and approval. At Buyer’s election, Xxxxx may develop the Corrective Action Plan. In no event shall Buyer and Supplier’s failure to agree on the Corrective Action Plan delay the timely notification of a potential safety hazard, non-compliance or Serial Defect to users of the goods, cause either party to be non-compliant with applicable Law or prevent Buyer from taking reasonable actions to prevent injury or damage to persons, equipment or other property. Supplier and Buyer shall cooperate with and assist each other in any corrective actions and/or filings, if applicable. (b) To the extent a recall is required by applicable Law, or due to a potential safety hazard, non-compliance or Serial Defect, which is caused by Supplier, Supplier shall indemnify and hold Buyer harmless from all reasonable costs and expenses incurred in connection with any recall, repair, replacement or refund program, including all costs related to: (i) investigating and/or inspecting the affected goods; (ii) notifying Buyer’s customers; (iii) repairing, or where repair of the goods is impracticable or impossible, repurchasing or replacing the recalled goods; (iv) packing and shipping the recalled goods; and (v) media notification. Each party shall consult the other before making any statements to the public or a governmental agency relating to such recall, potential safety hazard, non- compliance or Serial Defect, except where such consultation would prevent timely notification required by Law.

• Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.

• SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.

• Regulatory Materials (a) On a Program-by-Program basis, commencing on the Effective Date until the Regulatory Transfer Date, Prothena shall have the right, in consultation with Celgene, to prepare, file and maintain all Regulatory Materials (including any Regulatory Approvals) necessary for the Development and Manufacture of any Collaboration Candidates and Collaboration Products for such Program (collectively, the “Program Regulatory Materials”), and to interact with Regulatory Authorities in connection with the Development and Manufacture of any Collaboration Candidates and Collaboration Products for such Program. Prothena will provide Celgene with a reasonable opportunity to comment substantively on all material Regulatory Materials prior to filing or taking material action, and will reasonably and in good faith consider any comments and actions recommended by Celgene, including with respect to filing strategy. In addition, Prothena will allow Celgene or its representative to attend any and all meetings with Regulatory Authorities to the extent such attendance is not prohibited or limited by such Regulatory Authority. (b) If Celgene exercises its Phase 1 Portion Participation Right for a given Program, then immediately after such exercise, Prothena shall initiate the transfer of all Program Regulatory Materials, including for clarity any IND for the relevant Collaboration Candidates and/or Collaboration Products that are the subject of such Program to Celgene. The date on which such Program Regulatory Materials are transferred to Celgene shall be the “Regulatory Transfer Date” for such Program. Thereafter, Celgene shall have the right, in consultation with Prothena, to prepare, file, and maintain such Program Regulatory Materials, and to interact with Regulatory Authorities in connection with the Development and, as applicable, Manufacture of such Collaboration Candidates and Collaboration Products for such Program in accordance with the terms and conditions of Section 2.5. Additionally, with respect to any Phase 1 Clinical Trial conducted by Celgene pursuant to Section 2.5, Celgene will provide Prothena with a reasonable opportunity to comment substantively on all material Program Regulatory Materials prior to filing or taking material action, and will reasonably and in good faith consider any comments and actions recommended by Prothena, including with respect to filing strategy. In addition, with respect to any Phase 1 Clinical Trial conducted by Celgene pursuant to Section 2.5, Celgene will allow Prothena or its representative to attend any and all meetings with Regulatory Authorities to the extent such attendance is not prohibited or limited by such Regulatory Authority. For clarity, if the Regulatory Transfer Date does not occur prior to the expiration of the Option Term for such Program, Section 2.6.1(a) (and not this Section 2.6.1(b)) shall apply.

• Development Reports Beginning six months after Effective Date and ending on the date of first commercial sale of a Licensed Product in the United States, LICENSEE shall report to Cornell progress covering LICENSEE's (and Affiliate's and Sublicensee's) activities and efforts in the development of rights granted to LICENSEE under this Agreement for the preceding six months. The report shall include, but not be limited to, activities and efforts to develop and test all Licensed Products and obtain governmental approvals necessary for marketing the same. Such semi-annual reports shall be due within sixty days (60) of the reporting period and shall use the form as provided herein as Appendix C.