Protection Against Losses Sample Clauses

Protection Against Losses. Developer shall indemnify, defend and hold harmless the City, RDA, and their respective officers, employees, agents, attorneys, insurers and the successors and assigns of all of the foregoing, from any and all liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (hereinafter “Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by Developer of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations applicable to Developer’s obligations under this Agreement; or c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from Developer’s failure to comply with its obligations under this Agreement or otherwise.
Sample 1Sample 2Sample 3See All (25)
AutoNDA by SimpleDocs
Protection Against Losses. XXXX shall indemnify, defend and hold harmless the City, and its officers, employees, agents, attorneys, and insurers, from any and all suits, actions, legal or administrative proceedings, liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (hereinafter “Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by XXXX of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations applicable to XXXX’x obligations under this Agreement; or c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from XXXX’x failure to comply with its obligations under this Agreement or otherwise; d) Any act, omission, fault, or negligence of XXXX or of anyone acting under its direction or control or on its behalf, including its invitees. e) Any and all claims arising out of or resulting pursuant to the design or construction of the improvements, and/or the performance of the work specified in this Agreement. In any and all claims against the City, its officers, agents and employees by any employee of the XXXX, its contractors, subcontractors, anyone directly or indirectly employed by any of them, or anyone for whose acts any of them may be liable, the indemnification obligation under this section shall not be limited in any way by any limitation of the amount or type of damages, compensation or benefits payable for or for XXXX, its contractors or any subcontractor under Workers' Compensation Acts, disability benefit acts or other employee benefit acts.
Sample 1Sample 2
Protection Against Losses. Developer shall indemnify, defend and hold harmless the City and their respective officers, employees, agents, attorneys, insurers and the successors and assigns of all of the foregoing, from any and all liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (hereinafter “Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by Developer of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations applicable to Developer’s obligations under this Agreement; or c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from Developer’s failure to comply with its obligations under this Agreement or otherwise. Notwithstanding the foregoing, Xxxxxxxxx’s indemnification obligations hereunder shall be net of, and offset by the City’s contributing negligence, if any, and/or intentional misconduct, causing indemnifiable losses.
Sample 1Sample 2
Protection Against Losses. FOWLS shall indemnify, defend and hold harmless the City, and its officers, employees, agents, attorneys, and insurers, from any and all suits, actions, legal or administrative proceedings, liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (hereinafter “Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by FOWLS of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations applicable to FOWLS’s obligations under this Agreement; or c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from FOWLS’s failure to comply with its obligations under this Agreement or otherwise; d) Any act, omission, fault, or negligence of FOWLS or of anyone acting under its direction or control or on its behalf, including its invitees. e) Any and all claims arising pursuant to the design or construction of the improvements.
Sample 1
Protection Against Losses. BCPF shall indemnify, defend and hold harmless the City, and its respective officers, employees, agents, attorneys, and insurers, from any and all suits, actions, legal or administrative proceedings, liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (hereinafter “Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by BCPF of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations by BCPF prior to acceptance by the City; c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from BCPF’s failure to comply with its obligations under this Agreement or otherwise; d) Any act, omission, fault, or negligence of BCPF or of anyone acting under its direction or control or on its behalf, including its invitees prior to acceptance by the City; and/or e) Any and all claims arising pursuant to the design or construction of the Improvements.
Sample 1
Protection Against Losses. Owner shall indemnify, defend and hold harmless the City of Green Bay (“City”), RDA, and their respective officers, employees, agents, attorneys, insurers and the successors and assigns of all of the foregoing, from any and all liabilities, claims, losses, damages, judgments or awards, costs or expenses, including reasonable attorneys’ fees, of whatsoever nature and by whomsoever asserted, whether asserted by a third party or by a party to this Agreement (“Losses”), directly or indirectly, arising out of, resulting from or in any way connected with: a) Any breach by Owner of the terms of this Agreement; b) Any non-compliance with laws, ordinances, rules or regulations applicable to Owner’s obligations under this Agreement; or c) Any governmental, regulatory or other proceedings to the extent any such proceedings result from Owner’s failure to comply with its obligations under this Agreement or otherwise.
Sample 1

Related to Protection Against Losses

  • Protection Against Dilution If the Corporation, with respect to the Common Stock, (1) pays a dividend or makes a distribution on shares of Common Stock that is paid in shares of Common Stock or in securities convertible into or exchangeable for Common Stock (in which latter event the number of shares of Common Stock initially issuable upon the conversion or exchange of such securities shall be deemed to have been distributed), (2) subdivides outstanding shares of Common Stock, (3) combines outstanding shares of Common Stock into a smaller number of shares, or (4) issues by reclassification of Common Stock any shares of capital stock of the Corporation, the number of shares as to which this Warrant is exercisable as of the date of such event and the Exercise Price in effect immediately prior thereto shall be adjusted so that each Holder thereafter shall be entitled to receive the number and kind of shares of Common Stock or other capital stock of the Corporation that it would have owned or been entitled to receive in respect of this Warrant immediately after the happening of any of the events described above had this Warrant been converted immediately prior to the happening of that event; provided that the aggregate purchase price payable for the total numbers of shares of Common Stock purchasable under this Warrant shall remain the same. An adjustment made in accordance with this section shall become effective immediately after the record date, in the case of a dividend, and shall become effective immediately after the effective date, in the case of a subdivision, combination, or reclassification. If, as a result of an adjustment made in accordance with this Section 4, the Holder becomes entitled to receive shares of two or more classes of capital stock or shares of Common Stock and other capital stock of the Corporation, the board of directors (whose determination shall be conclusive) shall determine the allocation of the adjusted Exercise Rate between or among shares of such classes of capital stock or shares of Common Stock and other capital stock.

  • Claims Against Third Parties The Licensee shall, as soon as it becomes aware, give DACS in writing full particulars of any infringements or violations of any of DACS’ / the Artist’s rights in the Work.

  • Protection Against Loss of Future District Revenues Section 4.1. INTENT OF THE PARTIES. Subject to the limitations contained in this Agreement (including Section 7.1), it is the intent of the Parties that the District shall, in accordance with the provisions of TEXAS TAX CODE § 313.027(f)(1), be compensated by the Applicant for any loss that the District incurs in its Maintenance and Operations Revenue as a result of, or on account of, the Parties’ entering into this Agreement. Such compensation shall be independent of, and in addition to, all such other payments as are set forth in Article V and Article VI. Subject only to the limitations contained in this Agreement (including Section 7.1), it is the intent of the Parties that the risk of any negative financial consequence to the District as a result of Applicant’s location of Applicant’s Qualified Investment and Applicant’s Qualified Property in the District and the Parties’ entering into this Agreement will be borne by the Applicant and not by the District and be paid by the Applicant to the District in addition to any and all payments due under Article V and Article VI. The Parties expressly understand and agree that, for all Tax Years to which this Agreement may apply, the calculation of negative financial consequences will be defined for each applicable Tax Year in accordance with Applicable School Finance Law, as defined in Section 1.2 above, and that such definition specifically contemplates that calculations made under this Agreement may periodically change in accordance with changes in Applicable School Finance Law. The Parties further agree that printouts and projections produced during the negotiations and approval of this Agreement are: (i) for illustrative purposes only, are not intended to be relied upon, and have not been relied upon by the Parties as a prediction of future consequences to either Party; (ii) based upon current Applicable School Finance Law which is subject to change by statute, by administrative regulation (or interpretation thereof), or by judicial decision at any time; and (iii) may change in future years to reflect changes in Applicable School Finance Law. Section 4.2. CALCULATING THE AMOUNT OF LOSS OF MAINTENANCE AND OPERATIONS A. The Revenue Protection Amount owed by the Applicant to the District means the Original M&O Revenue minus the New M&O Revenue; Where:

  • Pursuit of Claims Against Third Parties If (i) a Party incurs any Liability arising out of this Agreement or any Ancillary Agreement; (ii) an adequate legal or equitable remedy is not available for any reason against the other Party to satisfy the Liability incurred by the incurring Party; and (iii) a legal or equitable remedy may be available to the other Party against a Third Party for such Liability, then the other Party shall use its commercially reasonable efforts to cooperate with the incurring Party, at the incurring Party’s expense, to permit the incurring Party to obtain the benefits of such legal or equitable remedy against the Third Party.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined). 22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees), (a) based on allegations that, if true, would establish (i) the Indemnifying Party’s breach of this Agreement; (ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct; (iii) the Indemnifying Party’s negligent or willful misconduct or omissions; (iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party; (v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or (vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or (b) that arises out of: (i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement; (ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement; (iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement; (iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or (v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)). 22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section. 22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.

  • Preferential Collection of Claims Against the Company The Trustee shall comply with Section 311(a) of the Trust Indenture Act, excluding any creditor relationship described in Section 311(b) of the Trust Indenture Act. A Trustee who has resigned or been removed shall be subject to Section 311(a) of the Trust Indenture Act to the extent included therein.

  • Uninsured Losses; Proceedings Against Assets There shall occur any material uninsured damage to or loss, theft or destruction of any of the Collateral in excess of $5,000,000 or the Collateral or any other of the Loan Parties’ or any of their Subsidiaries’ assets are attached, seized, levied upon or subjected to a writ or distress warrant; or such come within the possession of any receiver, trustee, custodian or assignee for the benefit of creditors and the same is not cured within thirty (30) days thereafter;

  • Complaints Against Teachers Communication between the Community and the School ideally should be such that most complaints may be resolved through personal conferences at the School level. Various avenues of contact between teacher, pupil, parent, principal and other appropriate staff personnel should be pursued before using the formal procedures outlined below. The following process shall not be used when allegations involve legal or criminal violations or allegations of misconduct towards a student, such as abuse or discrimination. Such allegations shall be investigated in accordance with board policy and in conjunction with the authorities, consistent with principles of due process. 1. The Complainant shall be given a copy of this Part II, Section J and be told that there are contractual requirements for the District to follow. 2. If such conferences do not lead to understanding and resolution of problems involved, a parent may pursue further action by submitting a complaint against a teacher, which must be submitted in writing to the principal of the school. The principal shall give a copy to the teacher. Likewise, the teacher may request in writing to the principal that such a written complaint must be filed or the matter shall be considered closed. The principal shall give a copy to the parent. 3. After a written complaint is filed, if requested by the complainant or the teacher, a meeting involving the teacher, the principal, and the complainant will be arranged as soon as possible to discuss the complaint. 4. If it is not resolved at that level to the satisfaction of the Complainant, the Complainant may appeal to the Superintendent. 5. If it is still unresolved to the satisfaction of the Complainant, the Complainant may appeal to the Board of Education.

  • Prohibition Against Recording Except as provided in Section 29.4 of this Lease, neither this Lease, nor any memorandum, affidavit or other writing with respect thereto, shall be recorded by Tenant or by anyone acting through, under or on behalf of Tenant.

  • Prohibition Against Discrimination It is the policy of the State to prohibit discrimination in employment against any employee or applicant for employment because of race, age, color, religion, creed, sex (including pregnancy), sexual orientation, political affiliation, country of national origin, ancestry, genetic information, gender identity or expression, mental or physical disability, marital status, or labor organization affiliations, and to promote and implement a positive and continuing program of equal employment opportunity. It is the policy of the Union that it shall not discriminate against any employee or cause or attempt to cause the State to discriminate against any employee because of race, age, color, religion, creed, sex, sexual orientation, political affiliation, country of national origin, ancestry, genetic information, gender identity or expression, mental or physical disability, marital status or labor or organization affiliation.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!