Informal Dispute Resolution Process 1. In the event there is a dispute under this Centralized Contract, the Contractor, OGS and Authorized User agree to exercise their best efforts to resolve the dispute as soon as possible. The Contractor, OGS and Authorized User shall, without delay, continue to perform their respective obligations under this Centralized Contract which are not affected by the dispute. Primary responsibility for resolving any dispute arising under this Centralized Contract shall rest with the Authorized User’s Contractor Coordinators and the Contractor’s Account Executive and the State & Local Government Regional General Manager.
2. In the event the Authorized User is dissatisfied with the Contractor’s Products provided under this Centralized Contract, the Authorized User shall notify the Contractor in writing pursuant to the terms of the Contract. In the event the Contractor has any disputes with the Authorized User, the Contractor shall so notify the Authorized User in writing. If either party notifies the other of such dispute, the other party shall then make good faith efforts to solve the problem or settle the dispute amicably, including meeting with the party’s representatives to attempt diligently to reach a satisfactory result through negotiation.
3. If negotiation between the Contractor and Authorized User fails to resolve any such dispute to the satisfaction of the parties within fourteen (14) business days or as otherwise agreed to by the Contractor and Authorized User, of such notice, then the matter shall be submitted to the State's Contract Administrator and the Contractor’s senior executive officer representative. Such representatives shall meet in person and shall attempt in good faith to resolve the dispute within the next fourteen (14) business days or as otherwise agreed to by the parties. This meeting must be held before either party may seek any other method of dispute resolution, including judicial or governmental resolutions. Notwithstanding the foregoing, this section shall not be construed to prevent either party from seeking and obtaining temporary equitable remedies, including injunctive relief.
4. The Contractor shall extend the informal dispute resolution period for so long as the Authorized User continues to make reasonable efforts to cure the breach, except with respect to disputes about the breach of payment of fees or infringement of its or its licensors’ intellectual property rights.
Informal Dispute Resolution (a) Prior to the initiation of formal dispute resolution procedures (i.e., arbitration), the Parties shall first attempt to resolve their dispute at the senior manager level. If that level of dispute resolution is not successful, the Parties shall proceed informally, as follows:
(i) Upon the written request of either Party, each Party shall appoint a designated representative who does not otherwise devote substantially full time to performance under this Agreement, whose task it will be to meet for the purpose of endeavoring to resolve such dispute.
(ii) The designated representatives shall meet as often as the Parties reasonably deem necessary in order to gather and furnish to the other all information with respect to the matter in issue that the Parties believe to be appropriate and germane in connection with its resolution. The representatives shall discuss the problem and attempt to resolve the dispute without the necessity of any formal proceeding.
(iii) During the course of discussion, all reasonable requests made by one Party to another for non-privileged non-confidential information reasonably related to this Agreement shall be honored so that each of the Parties may be fully advised of the other's position.
(iv) The specific format for the discussions shall be left to the discretion of the designated representatives.
(b) Prior to instituting formal proceedings, the Parties will first have their chief executive officers meet to discuss the dispute. This requirement shall not delay the institution of formal proceedings past any statute of limitations expiration or for more than fifteen (15) days.
(c) Subject to Subsection (b), formal proceedings for the resolution of a dispute may not be commenced until the earlier of:
(i) The designated representatives concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or
(ii) Thirty (30) days after the initial written request to appoint a designated representative pursuant to Subsection (a), above, (this period shall be deemed to run notwithstanding any claim that the process described in this Section 11.2 was not followed or completed).
(d) This Section 11.2 shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to avoid the expiration of any applicable limitations period, or to preserve a superior position with respect to other creditors or as provided in Section 11.6(a).
Dispute Resolution Procedures (a) In the event a dispute arises about the interpretation, application, calculation of Loss, or calculation of payments or otherwise with respect to this Single Family Shared-Loss Agreement (“SF Shared-Loss Dispute Item”), then the Receiver and the Assuming Institution shall make every attempt in good faith to resolve such items within sixty (60) days following the receipt of a written description of the SF Shared-Loss Dispute Item, with notification of the possibility of taking the matter to arbitration (the date on which such 60-day period expires, or any extension of such period as the parties hereto may mutually agree to in writing, herein called the “Resolution Deadline Date”). If the Receiver and the Assuming Institution resolve all such items to their mutual satisfaction by the Resolution Deadline Date, then within thirty (30) days following such resolution, any payment due as a result of such resolution shall be made arising from the settlement of the SF Shared-Loss Dispute.
(b) If the Receiver and the Assuming Institution fail to resolve any outstanding SF Shared-Loss Dispute Items by the Resolution Deadline Date, then either party may notify the other of its intent to submit the SF Shared-Loss Dispute Item to arbitration pursuant to the provisions of this Article VII. Failure of either party to submit pursuant to paragraph (c) hereof any unresolved SF Shared-Loss Dispute Item to arbitration within thirty (30) days following the Resolution Deadline Date (the date on which such thirty (30) day period expires is herein called the “Arbitration Deadline Date”) shall extinguish that party’s right to submit the non-submitted SF Shared-Loss Dispute Item to arbitration, and constitute a waiver of the submitting party’s right to dispute such non-submitted SF Shared-Loss Dispute Item (but not a waiver of any similar claim which may arise in the future).
(c) If a SF Shared-Loss Dispute Item is submitted to arbitration, it shall be governed by the rules of the American Arbitration Association (the “AAA”), except as otherwise provided herein. Either party may submit a matter for arbitration by delivering a notice, prior to the Arbitration Deadline Date, to the other party in writing setting forth:
(i) A brief description of each SF Shared-Loss Dispute Item submitted for arbitration;
(ii) A statement of the moving party’s position with respect to each SF Shared-Loss Dispute Item submitted for arbitration;
(iii) The value sought by the moving party, or other relief requested regarding each SF Shared-Loss Dispute Item submitted for arbitration, to the extent reasonably calculable; and
(iv) The name and address of the arbiter selected by the moving party (the “Moving Arbiter”), who shall be a neutral, as determined by the AAA. Failure to adequately include any information above shall not be deemed to be a waiver of the parties right to arbitrate so long as after notification of such failure the moving party cures such failure as promptly as reasonably practicable.
(d) The non-moving party shall, within thirty (30) days following receipt of a notice of arbitration pursuant to this Section 7.1, deliver a notice to the moving party setting forth:
(i) The name and address of the arbiter selected by the non-moving party (the “Respondent Arbiter”), who shall be a neutral, as determined by the AAA;
(ii) A statement of the position of the respondent with respect to each Dispute Item; and
(iii) The ultimate resolution sought by the respondent or other relief, if any, the respondent deems is due the moving party with respect to each SF Shared-Loss Dispute Item. Failure to adequately include any information above shall not be deemed to be a waiver of the non-moving party’s right to defend such arbitration so long as after notification of such failure the non-moving party cures such failure as promptly as reasonably practicable
(e) The Moving Arbiter and Respondent Arbiter shall select a third arbiter from a list furnished by the AAA. In accordance with the rules of the AAA, the three (3) arbiters shall constitute the arbitration panel for resolution of each SF Loss-Share Dispute Item. The concurrence of any two (2) arbiters shall be deemed to be the decision of the arbiters for all purposes hereunder. The arbitration shall proceed on such time schedule and in accordance with the Rules of Commercial Arbitration of the AAA then in effect, as modified by this Section 7.1. The arbitration proceedings shall take place at such location as the parties thereto may mutually agree, but if they cannot agree, then they will take place at the offices of the Corporation in Washington, DC, or Arlington, Virginia.
(f) The Receiver and Assuming Institution shall facilitate the resolution of each outstanding SF Shared-Loss Dispute Item by making available in a prompt and timely manner to one another and to the arbiters for examination and copying, as appropriate, all documents, books, and records under their respective control and that would be discoverable under the Federal Rules of Civil Procedure.
Dispute Procedures Contact Think with any questions concerning this Agreement or the Services by calling 0- 000-000-0000 (toll-free), Monday - Friday 8AM – 8PM ET (note these hours may change); by sending a letter to Think, P. O. Box 1288, Greens Farms, Connecticut 06838; or by sending an email to: xxxx@xxxxxxxxxxx.xxx. Think will refer all complaints and inquiries to a representative who will attempt to reach a mutually satisfactory resolution. If your complaint or inquiry is not resolved after you have called Think and/or the EDC, or for general information, you may contact the DPU for assistance toll-free at (000) 000-0000, or at XXXXxxxxxxx.Xxxxxxxxxx@xxxx.xxx, or by sending a letter to the DPU at: 0 Xxxxx Xxxxxxx, 0xx Xxxxx Xxxxxx, XX 00000. You have a right to make a formal or informal complaint to the DPU or any regulatory body with authority to review your complaint. In addition, mediation is available for disputes greater than $100. Nothing in the Arbitration, Waiver of Jury Trial, and Class Action Waiver Section below is intended to bar your right to make a complaint or request mediation. ARBITRATION. Think’s Arbitration and Class Action Wavier Policy Addendum, which is available and provided to you during the enrollment process is incorporated herein and made a part hereof, contains additional details and a complete description of the terms and conditions of the Arbitration and Class Action Waiver Policy, including your ability to opt out. Warranties. THINK MAKES NO EXPRESS REPRESENTATION OR WARRANTIES WITH REGARD TO THE PROVISION OF ELECTRIC SERVICE AND DISCLAIMS ANY AND ALL WARRANTIES, EXPRESSED OR IMPLIED, OR ARISING OUT OF ANY COURSE OF DEALING OR USAGE OF TRADE EXCEPT WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Limitation of Liability. You will be deemed to be in exclusive control (and responsible for any damages or injury caused thereby) of the electric power after receipt at the delivery point(s). TO THE FULLEST EXTENT PERMITTED BY LAW, THINK WILL NOT BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, PUNITIVE, EXEMPLARY, OR INDIRECT DAMAGES (INCLUDING LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES), WHETHER BY STATUTE, IN CONTRACT OR TORT, EVEN IF THE RESULT OF NEGLIGENCE (WHETHER SOLE, JOINT, CONCURRENT, ACTIVE, OR PASSIVE). ALL OTHER LIABILITY WILL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, AND SUCH DIRECT ACTUAL DAMAGES WILL BE THE SOLE AND EXCLUSIVE REMEDY. YOU HEREBY WAIVE ALL OTHER REMEDIES AT LAW OR IN EQUITY. THERE ARE NO THIRD-PARTY BENEFICIARIES TO THIS AGREEMENT. To the extent any damages required to be paid hereunder are liquidated, the Parties acknowledge that the damages are not intended and shall not be construed as a penalty, such damages are difficult or impossible to determine, that otherwise obtaining an adequate remedy is inconvenient or impossible, and that the liquidated damages constitute a reasonable approximation of the harm or loss.
Alternative Dispute Resolution Prior to filing of litigation, the parties may select non-binding mediation as a method of conflict resolution for issues arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction. The parties agree that if non-binding mediation is chosen as a resolution process, the parties must agree to the chosen mediator(s) and that all mediation venue shall be at a location in Xxx Xxxxx County, Texas or agreed by the parties. The parties agree to share equally the cost of the mediation process and venue cost.
Informal Procedures A. The grievant should first discuss the matter with his/her principal or administrator or supervisor to whom he/she is directly responsible in an effort to resolve the problem informally.
B. If the grievant is not satisfied with the disposition of the matter, he/she shall have the right to have a representative of his/her choice to assist him/her in further efforts to resolve the problem informally with the principal or other appropriate administrator or supervisor.
Initial Dispute Resolution If a dispute arises out of or relates to this Contract or its breach, the parties shall endeavor to settle the dispute first through direct discussions between the parties’ representatives who have the authority to settle the dispute. If the parties’ representatives are not able to promptly settle the dispute, they shall refer the dispute to the senior administrators of the parties who have the authority to settle the dispute, who shall meet within fourteen days thereafter. If the dispute is not settled by the senior administrators, the parties may submit the dispute to mediation in accordance with Paragraph 5.2.3.2.
Informal Negotiations To expedite resolution and control the cost of any dispute, controversy, or claim related to these Terms of Use (each a "Dispute" and collectively, the “Disputes”) brought by either you or us (individually, a “Party” and collectively, the “Parties”), the Parties agree to first attempt to negotiate any Dispute (except those Disputes expressly provided below) informally for at least thirty (30) days before initiating arbitration. Such informal negotiations commence upon written notice from one Party to the other Party.
Negotiation; Alternative Dispute Resolution The Parties will attempt in good faith to resolve any dispute or controversy arising out of or relating to the performance of services under this Agreement. If the Parties are unable to resolve the dispute, then, pursuant to San Francisco Administrative Code Section 21.36, Contractor may submit to the Contracting Officer a written request for administrative review and documentation of the Contractor's claim(s). Upon such request, the Contracting Officer shall promptly issue an administrative decision in writing, stating the reasons for the action taken and informing the Contractor of its right to judicial review. If agreed by both Parties in writing, disputes may be resolved by a mutually agreed-upon alternative dispute resolution process. If the parties do not mutually agree to an alternative dispute resolution process or such efforts do not resolve the dispute, then either Party may pursue any remedy available under California law. The status of any dispute or controversy notwithstanding, Contractor shall proceed diligently with the performance of its obligations under this Agreement in accordance with the Agreement and the written directions of the City. Neither Party will be entitled to legal fees or costs for matters resolved under this section.
Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.
