Default Remedies Termination If the Stop Work Order is canceled, ODHS may, after receiving and evaluating a request by the Contractor, make an adjustment in the time required to complete this Contract and the Contract price by a duly executed amendment.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Effect of Resignation or Removal With effect from the Resignation Effective Date or the Removal Effective Date (as applicable) (i) the retiring or removed Administrative Agent shall be discharged from its duties and obligations hereunder and under the other Loan Documents (except that in the case of any collateral security held by the Administrative Agent on behalf of the Lenders or the L/C Issuer under any of the Loan Documents, the retiring or removed Administrative Agent shall continue to hold such collateral security until such time as a successor Administrative Agent is appointed) and (ii) except for any indemnity payments or other amounts then owed to the retiring or removed Administrative Agent, all payments, communications and determinations provided to be made by, to or through the Administrative Agent shall instead be made by or to each Lender and the L/C Issuer directly, until such time, if any, as the Required Lenders appoint a successor Administrative Agent as provided for above. Upon the acceptance of a successor’s appointment as Administrative Agent hereunder, such successor shall succeed to and become vested with all of the rights, powers, privileges and duties of the retiring (or removed) Administrative Agent (other than as provided in Section 3.01(g) and other than any rights to indemnity payments or other amounts owed to the retiring or removed Administrative Agent as of the Resignation Effective Date or the Removal Effective Date, as applicable), and the retiring or removed Administrative Agent shall be discharged from all of its duties and obligations hereunder or under the other Loan Documents (if not already discharged therefrom as provided above in this Section 9.06). The fees payable by the Borrower to a successor Administrative Agent shall be the same as those payable to its predecessor unless otherwise agreed between the Borrower and such successor. After the retiring or removed Administrative Agent’s resignation or removal hereunder and under the other Loan Documents, the provisions of this Article XI and Section 11.04 shall continue in effect for the benefit of such retiring or removed Administrative Agent, its sub-agents and their respective Related Parties in respect of any actions taken or omitted to be taken by any of them (A) while the retiring or removed Administrative Agent was acting as Administrative Agent and (B) after such resignation or removal for as long as any of them continues to act in any capacity hereunder or under the other Loan Documents, including, without limitation, (1) acting as collateral agent or otherwise holding any collateral security on behalf of any of the Secured Parties and (2) in respect of any actions taken in connection with transferring the agency to any successor Administrative Agent.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
Certain Rules Relating to the Payment of Additional Amounts (a) If any Affected Person requests compensation under Section 5.01, or if the Borrower is required to pay any additional amount to any Affected Person or to any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, then such Affected Person shall (at the request of the Borrower) use commercially reasonable efforts to designate a different lending office for funding or booking the related Loans hereunder or to assign and delegate (or cause to be assigned and delegated) such Affected Person’s rights and obligations hereunder to another office, branch or Affiliate of such Affected Person if, in the judgment of such Affected Person, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 5.01 or 5.03, as the case may be, in the future and (ii) would not subject such Affected Person to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Affected Person. The Borrower hereby agrees to pay all reasonable out of pocket costs and expenses incurred by any Affected Person in connection with any such designation or assignment and delegation.
(b) If (i) any Affected Person requests compensation under Section 5.01, (ii) the Borrower is required to pay any additional amount to any Affected Person or any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, (iii) any Affected Person has become a Defaulting Lender or (iv) any Affected Person has failed to consent to a proposed amendment, waiver, discharge or termination that requires the consent of all Lenders and with respect to which the other Lenders shall have or would have granted their consent, then the Borrower may, at its sole expense and effort, upon notice to the Administrative Agent, require the Administrative Agent to cause the related Affected Person to assign and delegate, without recourse (in accordance with and subject to all applicable transfer restrictions), all its interests, rights and obligations under this Agreement and the other Transaction Documents to another appropriate Person (which, in the case of a Lender, shall be an Eligible Assignee) that shall acquire such interest or assume such commitment; provided that (a) the Borrower shall have received the prior written consent of the Administrative Agent and the other Lenders, which consent shall not unreasonably be withheld, (b) such Affected Person, if a Lender, shall have received payment of an amount equal to its outstanding Capital and, if applicable, accrued Interest and Fees thereon and all other amounts then owing to it hereunder from the assignee or the Borrower, (c) in the case of any such assignment and delegation resulting from a claim for compensation under Section 5.01 or payments required to be made pursuant to Section 5.03, such assignment is expected to result in a reduction in such compensation or payments for future periods and (d) in the case of any such assignment and delegation resulting from the failure of an Affected Person to provide a consent, the assignee shall have given such consent and, as a result of such assignment and delegation and any contemporaneous assignments and delegations and consents, the applicable amendment, waiver, discharge or termination can be effected. An Affected Person shall not be required to make any such assignment and delegation if, prior thereto, as a result of a waiver or consent by such Affected Person or otherwise, the circumstances entitling the Borrower to require such assignment and delegation have ceased to apply.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
A. The Application, any Application Supplement, or any Application Amendment on which this Agreement is approved is determined to be inaccurate as to any material representation, information, or fact or is not complete as to any material fact or representation or such application;
B. The Applicant failed to complete Qualified Investment as required by Section 2.5.A. of this Agreement during the Qualifying Time Period;
C. The Applicant failed to create and maintain the number of New Qualifying Jobs required by the Act;
D. The Applicant failed to create and maintain the number of New Qualifying Jobs specified in Schedule C of the Application;
E. The Applicant failed to pay at least the average weekly wage of all jobs in the county in which the jobs are located for all New Non-Qualifying Jobs created by the Applicant;
F. The Applicant failed to provide payments to the District sufficient to protect future District revenues through payment of revenue offsets and other mechanisms as more fully described in Article IV of this Agreement;
G. The Applicant failed to provide the payments to the District that protect the District from the payment of extraordinary education-related expenses related to the project to the extent and in the amounts that the Applicant agreed to provide such payments in Article V of this Agreement;
H. The Applicant failed to provide the Supplemental Payments to the extent and in the amounts that the Applicant agreed to provide such Supplemental Payments in Article VI of this Agreement;
I. The Applicant failed to create and Maintain Viable Presence on or with the Qualified Property as more fully specified in Article VIII of this Agreement;
J. The Applicant failed to submit the reports required to be submitted by Section 8.2 to the satisfaction of the Comptroller;
K. The Applicant failed to provide the District or the Comptroller with all information reasonably necessary for the District or the Comptroller to determine whether the Applicant is in compliance with its obligations, including, but not limited to, any employment obligations which may arise under this Agreement;
L. The Applicant failed to allow authorized employees of the District, the Comptroller, the Appraisal District, or the State Auditor’s Office to have access to the Applicant’s Qualified Property or business records in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property under Sections 8.5 and 8.6;
M. The Applicant failed to comply with a request by the State Auditor’s office to review and audit the Applicant’s compliance with this Agreement;
N. The Applicant has made any payments to the District or to any other person or persons in any form for the payment or transfer of money or any other thing of value in recognition of, anticipation of, or consideration for this Agreement for limitation on Appraised Value made pursuant to Chapter 313 of the TEXAS TAX CODE, in excess of the amounts set forth in Articles IV, V and VI of this Agreement;
O. The Applicant failed to comply with the conditions included in the certificate for limitation issued by the Comptroller.
Suspension or Termination of Sales Consistent with standard market settlement practices, the Company or the Agent may, upon notice to the other party hereto in writing or by telephone (confirmed immediately by verifiable email), suspend any sale of Shares, and the period set forth in an Issuance Notice shall immediately terminate; provided, however, that (A) such suspension and termination shall not affect or impair either party’s obligations with respect to any Shares placed or sold hereunder prior to the receipt of such notice; (B) if the Company suspends or terminates any sale of Shares after the Agent confirms such sale to the Company, the Company shall still be obligated to comply with Section 3(b)(v) with respect to such Shares; and (C) if the Company defaults in its obligation to deliver Shares on a Settlement Date, the Company agrees that it will hold the Agent harmless against any loss, claim, damage or expense (including, without limitation, penalties, interest and reasonable legal fees and expenses), as incurred, arising out of or in connection with such default by the Company. The parties hereto acknowledge and agree that, in performing its obligations under this Agreement, the Agent may borrow Common Shares from stock lenders in the event that the Company has not delivered Shares to settle sales as required by subsection (v) above, and may use the Shares to settle or close out such borrowings. The Company agrees that no such notice shall be effective against the Agent unless it is made to the persons identified in writing by the Agent pursuant to Section 3(b)(i).
CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1. The Effective Date of this Settlement Agreement shall not occur unless and until each and every one of the following events occurs:
(a) This Agreement has been signed by the Parties and Class Counsel, and the individual settlement agreements with Xxxxxxxxx Xxxxx, the heirs of Xxxxx Xxxxx, Xxxxxx Xxxxxxxxx, and Xxxxxx Xxxxxxxx-Xxx have been fully executed;
(b) The Court has entered an order granting Preliminary Approval of the Agreement;
(c) The Court has entered a Final Approval Order finally approving the Agreement, or a judgment substantially consistent with this Settlement Agreement that has become final and unappealable, following Notice and a Final Approval Hearing, as provided in the Federal Rules of Civil Procedure; and
(d) In the event that the Court enters an approval order and final judgment in a form other than that provided above (“Alternative Approval Order”) to which the Parties have consented, that Alternative Approval Order has become final and unappealable.
9.2. If some or all of the conditions specified in Paragraph 9.1 are not met, or in the event that this Settlement Agreement is not approved by the Court, or the settlement set forth in this Agreement is terminated or fails to become effective in accordance with its terms, then this Settlement Agreement shall be canceled and terminated subject to Paragraph 9.3, unless Class Counsel and Defendant’s Counsel mutually agree in writing to proceed with this Agreement. If any Party is in material breach of the terms hereof, any other Party, provided that it is in substantial compliance with the terms of this Agreement, may terminate this Agreement on notice to all other Parties. Notwithstanding anything herein, the Parties agree that the Court’s decision as to the amount of the Illinois Fee Award and Ohio Fee Award to Class Counsel set forth above or the incentive award to the Class Representatives, regardless of the amounts awarded, shall not prevent the Agreement from becoming effective, nor shall it be grounds for termination of the Agreement.
9.3. If this Agreement is terminated or fails to become effective for the reasons set forth in Paragraphs 6.1, 6.2, 9.1, or 9.2 above, the Parties shall be restored to their respective positions in the Action as of the date of the signing of this Agreement. In such event, any Final Approval Order or other order entered by the Court in accordance with the terms of this Agreement shall be treated as vacated, nunc pro tunc, and the Parties shall be returned to the status quo ante with respect to the Actions as if this Agreement had never been entered into, including Defendant’s right to seek to compel arbitration as to the Plaintiffs named in the Second Amended Complaint.
9.4. In the event the Settlement is terminated or fails to become effective for any reason, the Illinois Settlement Fund and Ohio Settlement Fund, together with any earnings thereon at the same rate as earned, less any taxes paid or due, less Settlement Administrative Expenses actually incurred and paid or payable from the Settlement Fund, shall be returned to Defendant or its Insurer within thirty (30) calendar days after written notification of such event in accordance with instructions provided by Defendant’s Counsel to the Settlement Administrator.
Action upon Termination or Removal Promptly upon the effective date of termination of this Agreement pursuant to Section 8, or the removal or resignation of the Administrator pursuant to Section 8, the Administrator shall be entitled to be paid by the Servicer all fees accruing to it to the date of such termination or removal.
