CLEC Certification 8.1 Notwithstanding any other provision of this Agreement, CenturyLink shall have no obligation to perform under this Agreement until such time as CLEC has obtained such FCC and Commission authorization(s) as may be required by Applicable Law for conducting business in the State as a competitive local exchange carrier. CLEC shall not be permitted to establish its account nor place any orders under this Agreement until it has obtained such authorization and provided proof of such to CenturyLink. For the life of this Agreement, CLEC must represent and warrant to CenturyLink that it remains a certified local provider of Telephone Exchange Service within CenturyLink’s Local Calling Area(s) in the State. At any time during the life of this Agreement, CLEC will provide a copy of its current Certificate of Operating Authority or other evidence of its status to CenturyLink upon request. CLEC’s failure to maintain such authorization(s) as may be required by Applicable Law for conducting business in the State as a CLEC shall be considered a Default of Agreement.
Class Certification Solely for the purposes of this Settlement, the Parties stipulate and agree to certification of the claims asserted on behalf of Class Members. As such, the Parties stipulate and agree that in order for this Settlement to occur, the Court must certify the Class as defined in this Agreement.
Prepayment Certificate Concurrently with any prepayment of the Loans pursuant to Sections 2.14(a) through 2.14(e), Borrower shall deliver to Administrative Agent a certificate of an Authorized Officer demonstrating the calculation of the amount of the applicable net proceeds or Consolidated Excess Cash Flow, as the case may be. In the event that Borrower shall subsequently determine that the actual amount received exceeded the amount set forth in such certificate, Borrower shall promptly make an additional prepayment of the Loans in an amount equal to such excess, and Borrower shall concurrently therewith deliver to Administrative Agent a certificate of an Authorized Officer demonstrating the derivation of such excess.
Settlement Class Certification The Settling Parties agree, for purposes of this settlement only, to the certification of the Settlement Class. If the settlement set forth in this Settlement Agreement is not approved by the Court, or if the Settlement Agreement is terminated or cancelled pursuant to the terms of this Settlement Agreement, this Settlement Agreement, and the certification of the Settlement Class provided for herein, will be vacated and the Litigation shall proceed as though the Settlement Class had never been certified, without prejudice to any Person’s or Settling Party’s position on the issue of class certification or any other issue. The Settling Parties’ agreement to the certification of the Settlement Class is also without prejudice to any position asserted by the Settling Parties in any other proceeding, case or action, as to which all of their rights are specifically preserved.
Provisional Certificate 12.2.1 Subject to the provisions of Clause 12.2.5, upon completion of all Works forming part of the Project Highway, save and except the Works for which Time Extension has been granted under Clause 10.5, the Authority’s Engineer shall, at the request of the Contractor, issue a provisional certificate of completion substantially in the form set forth in Schedule-L (the “Provisional Certificate”) if the Tests for and in respect of the completed Works are successful. The Provisional Certificate shall have appended thereto a list of outstanding items of work (the “Punch List”) that need to be completed in accordance with the provisions of this Agreement. The Contractor undertakes to complete the minor outstanding items of works in respect of those Sections of the Project Highway for which the Provisional Certificate has been issued, within a period of 30 (thirty) days of the date of Provisional Certificate, and those parts of the Works in respect of which Time Extension has been granted, within the extended period thereof. For the avoidance of doubt, the Parties agree that the Punch List shall include all Works for which Time Extension has been granted and shall also include any minor outstanding items of work forming part of the completed Sections if such works do not materially affect the use of the completed Sections for their intended purpose. The Parties further agree that Provisional Certificate shall not be issued if the completed Works cannot be safely and reliably placed in service of the Users thereof. 12.2.2 Upon issue of Provisional Certificate, the provisions of Articles 14 and 17 shall apply to the completed parts of the Project Highway and the property and ownership of all such completed Works shall vest in the Authority. 12.2.3 If the Authority’s Engineer determines that the Project Highway or any completed part thereof does not conform to the provisions of this Agreement and cannot be safely and reliably placed in operation, it shall forthwith make a report in this behalf and send copies thereof to the Authority and the Contractor and withhold issuance of the Provisional Certificate until the Defects or deficiencies are rectified by the Contractor and Tests are successful in accordance with this Article 12. 12.2.4 Notwithstanding anything to the contrary contained in Clause 12.2.3, the Authority may, at any time after receiving a report from the Authority’s Engineer under that Xxxxxx, direct the Authority’s Engineer to issue a Provisional Certificate under Clause 12.2.1 and such direction shall be complied forthwith. 12.2.5 No Provisional Certificate shall be issued under the provisions of this Clause 12.2 until the Contractor has submitted valid claims for payment of at least 80% (eighty per cent) of the amount arrived at after reducing the lump sum price specified in Clause 19.1.1 by the amount attributable to works which have been withdrawn under the provisions of Clause 8.3.3. For the avoidance of doubt and by way of illustration, the Parties agree that if the Contract Price specified in Clause 19.1.1 is Rs. 105 cr. (Rs. one hundred and five crore) and the works withdrawn under Clause 8.3.3 have a value of Rs. 5 cr. (Rs. five crore), a Provisional Certificate shall not be issued until valid claims for payment of an amount of Rs. 80 cr. (Rs. eighty crore) have been submitted by the Contractor in accordance with the provisions of this Agreement. It is further agreed that all price adjustments made in pursuance of Clause 19.10 shall not be reckoned for computation of the claims for payments referred to in this Clause 12.2.5.
Replacement Certificates If, on the date a Securityholder’s escrow securities are to be released, the Escrow Agent holds a share certificate or other evidence representing more escrow securities than are to be released, the Escrow Agent will deliver the share certificate or other evidence to the Issuer or its transfer agent and request replacement share certificates or other evidence. The Issuer will cause replacement share certificates or other evidence to be prepared and delivered to the Escrow Agent. After the Escrow Agent receives the replacement share certificates or other evidence, the Escrow Agent will send to the Securityholder or at the Securityholder’s direction, the replacement share certificate or other evidence of the escrow securities released. The Escrow Agent and Issuer will act as soon as reasonably practicable.
Exhibit D - Debarment Certification By signing and submitting this Contract, the Contractor is agreeing to abide by the debarment requirements as set out below.
AS9100 Certification AS9100 Certification, specifies requirements for a quality management system to demonstrate the Contractor’s ability to consistently meet the customer requirements as well as statutory and regulatory requirements for the aerospace industry. An AS9100 Certification, is not mandatory; however, Contractors who desire to compete for work within the aerospace industry are encouraged to have AS9100 Certification, during the entire term of OASIS. The Contractor shall notify the OASIS CO, in writing, if there are any changes in the status of their AS9100 Certification, and provide the reasons for the change and copies of audits from an AS9100 Certification Body, as applicable. If only part of a Contractor’s organization is AS9100, certified, the Contractor shall make the distinction between which business units or sites and geographic locations have been certified.
Non-Book Entry Certificate to Global Certificate If a holder of a Non-Book Entry Certificate that is a Private Certificate (other than any Risk Retention Certificate during the RR Interest Transfer Restriction Period, a Class S Certificate or a Class R Certificate) wishes at any time to exchange its interest in such Non-Book Entry Certificate for an interest in a Global Certificate of the same Class, or to transfer all or part of such Non-Book Entry Certificate to an institution that is entitled to take delivery thereof in the form of an interest in a Global Certificate, such holder may, subject to the rules and procedures of Euroclear or Clearstream, if applicable, and the Depository, cause the exchange of all or part of such Non-Book Entry Certificate for an equivalent beneficial interest in the appropriate Global Certificate of the same Class. Upon receipt by the Certificate Registrar, as registrar, at its office designated in Section 5.11 of this Agreement, of (1) such Non-Book Entry Certificate, duly endorsed as provided herein, (2) instructions from such holder directing the Certificate Registrar, as registrar, to credit, or cause to be credited, a beneficial interest in the applicable Global Certificate equal to the portion of the Certificate Balance of the Non-Book Entry Certificate to be exchanged, such instructions to contain information regarding the participant account with the Depository to be credited with such increase and (3) a certificate in the form of Exhibit I to this Agreement (in the event that the applicable Global Certificate is the Temporary Regulation S Global Certificate), in the form of Exhibit J to this Agreement (in the event that the applicable Global Certificate is the Regulation S Global Certificate) or in the form of Exhibit K to this Agreement (in the event that the applicable Global Certificate is the Rule 144A Global Certificate), then the Certificate Registrar, as registrar, shall cancel, or cause to be canceled, all or part of such Non-Book Entry Certificate, and shall, if applicable, direct the Certificate Administrator to execute, authenticate and deliver to the transferor a new Non-Book Entry Certificate equal to the aggregate Certificate Balance of the portion retained by such transferor and shall instruct the Depository to increase, or cause to be increased, such Global Certificate by the aggregate Certificate Balance of the portion of the Non-Book Entry Certificate to be exchanged and to credit, or cause to be credited, to the account of the institution specified in such instructions a beneficial interest in the applicable Global Certificate equal to the Certificate Balance of the portion of the Non-Book Entry Certificate so canceled.
OFAC Certification Company certifies that (i) it is not acting on behalf of any person, group, entity, or nation named by any Executive Order or the United States Treasury Department, through its Office of Foreign Assets Control (“OFAC”) or otherwise, as a terrorist, “Specially Designated Nation”, “Blocked Person”, or other banned or blocked person, entity, nation, or transaction pursuant to any law, order, rule or regulation that is enforced or administered by OFAC or another department of the United States government, and (ii) Company is not engaged in this transaction on behalf of, or instigating or facilitating this transaction on behalf of, any such person, group, entity or nation.
