CERTIFICATION REGARDING DEBARMENT OR SUSPENSION Contractor certifies that neither Contractor or its principals; its subcontractors or their principals; the sub-recipients (if applicable) or their principals are suspended, debarred, proposed for debarment, voluntarily excluded from covered transactions, or otherwise disqualified by any federal department or agency from doing business with the Federal Government pursuant to Executive Orders 12549 and 12689. Contractor specifically covenants that neither the Contractor or its principals, its sub-contractors or their principals, or the sub-recipients (if applicable) or their principals are included on the Excluded Parties List System (“EPLS”) maintained by the General Services Administration (“GSA”).
Notice of Suspension The importer and the applicant shall be promptly notified of the suspension of the release of goods according to Article 51.
BANKRUPTCY, DEBARMENT, OR SUSPENSION CERTIFICATION Supplier certifies and warrants that it is not in bankruptcy or that it has previously disclosed in writing certain information to Sourcewell related to bankruptcy actions. If at any time during this Contract Supplier declares bankruptcy, Supplier must immediately notify Sourcewell in writing. Supplier certifies and warrants that neither it nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from programs operated by the State of Minnesota; the United States federal government or the Canadian government, as applicable; or any Participating Entity. Supplier certifies and warrants that neither it nor its principals have been convicted of a criminal offense related to the subject matter of this Contract. Supplier further warrants that it will provide immediate written notice to Sourcewell if this certification changes at any time.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted.
§ 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice.
§ 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination.
§ 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause.
§ 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements.
§ 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
NON-SUSPENSION OR DEBARMENT CERTIFICATION The City of Xxxxxx is prohibited from contracting with or making prime or sub-awards to parties that are suspended or debarred or whose principals are suspended or debarred from Federal, State, or City of Xxxxxx Contracts. By accepting a Contract with the City, the Vendor certifies that its firm and its principals are not currently suspended or debarred from doing business with the Federal Government, as indicated by the General Services Administration List of Parties Excluded from Federal Procurement and Non-Procurement Programs, the State of Texas, or the City of Xxxxxx.
Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.
CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.
Notice of Certain Events Affecting Registration; Suspension of Right to Make an Advance The Company will immediately notify the Investor upon its becoming aware of the occurrence of any of the following events in respect of a registration statement or related prospectus relating to an offering of Registrable Securities: (i) receipt of any request for additional information by the SEC or any other Federal or state governmental authority during the period of effectiveness of the Registration Statement for amendments or supplements to the registration statement or related prospectus; (ii) the issuance by the SEC or any other Federal or state governmental authority of any stop order suspending the effectiveness of the Registration Statement or the initiation of any proceedings for that purpose; (iii) receipt of any notification with respect to the suspension of the qualification or exemption from qualification of any of the Registrable Securities for sale in any jurisdiction or the initiation or threatening of any proceeding for such purpose; (iv) the happening of any event that makes any statement made in the Registration Statement or related prospectus of any document incorporated or deemed to be incorporated therein by reference untrue in any material respect or that requires the making of any changes in the Registration Statement, related prospectus or documents so that, in the case of the Registration Statement, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein not misleading, and that in the case of the related prospectus, it will not contain any untrue statement of a material fact or omit to state any material fact required to be stated therein or necessary to make the statements therein, in the light of the circumstances under which they were made, not misleading; and (v) the Company's reasonable determination that a post-effective amendment to the Registration Statement would be appropriate; and the Company will promptly make available to the Investor any such supplement or amendment to the related prospectus. The Company shall not deliver to the Investor any Advance Notice during the continuation of any of the foregoing events.
Suspension of Solicitation; Amendment or Supplement The Company may instruct the Agents to suspend solicitation of offers to purchase Notes at any time, whereupon the Agents will as promptly as possible (but in any event not later than one business day after receipt of such instruction) suspend solicitation until such time as the Company has advised the Agents that solicitation of offers to purchase Notes may be resumed. If the Company proposes to amend or supplement the Registration Statement or the Prospectus relating to the Notes (except in the case of a Pricing Supplement), it will promptly advise the Agents and will furnish to the Agents such proposed amendment or supplement and, after the Agents have been afforded a reasonable opportunity to review such amendment or supplement, will cause such amendment or supplement to be filed with the Commission. The Company will promptly provide the Agents with copies of any such amendment or supplement and confirm to the Agents that such amendment or supplement has been filed with the Commission. In the event that at the time the Agents suspend solicitation of offers to purchase Notes there shall be any outstanding offers to purchase Notes that have been accepted by the Company but for which settlement has not occurred, the Company, consistent with its obligations under the Distribution Agreement, promptly will advise the Agents whether such sales may be settled and whether copies of the Prospectus as supplemented at the time of the suspension may be delivered in connection with the settlement of such sales. The Company will have the sole responsibility for such decision and for any arrangements which may be made in the event that the Company determines that such sales may not be settled or that copies of such Prospectus may not be so delivered. Authenticity of Signatures: The Trustee will furnish the Agents from time to time with the specimen signatures of each of the Trustee's officers, employees or agents who have been authorized by the Trustee to authenticate Notes, but the Agents will have no obligation or liability to the Company or the Trustee in respect of the authenticity of the signature of any officer, employee or agent of the Company or the Trustee on any Note.
Service Termination, Cancellation, or Suspension If you wish to cancel the Service, you may contact us as set forth in Section 6 of the General Terms above. Any payment(s) that have begun processing before the requested cancellation date will be processed by us. You agree that we may terminate or suspend your use of the Service at any time and for any reason or no reason. Neither termination, cancellation nor suspension shall affect your liability or obligations under this Agreement.
