Repair Obligation If neither party elects to terminate this Lease following a Casualty, then Landlord shall, within a reasonable time after such Casualty, begin to repair the Premises and shall proceed with reasonable diligence to restore the Premises to substantially the same condition as they existed immediately before such Casualty; however, Landlord shall not be required to repair or replace any improvements, alterations or betterments within the Premises (which shall be promptly and with due diligence repaired and restored by Tenant at Tenant’s sole cost and expense) or any furniture, equipment, trade fixtures or personal property of Tenant or others in the Premises or the Project, and Landlord’s obligation to repair or restore the Premises shall be limited to the extent of the insurance proceeds actually received by Landlord for the Casualty in question. If this Lease is terminated under the provisions of this Section 15, Landlord shall be entitled to the full proceeds of the insurance policies providing coverage for all alterations, improvements and betterments in the Premises (and, if Tenant has failed to maintain insurance on such items as required by this Lease, Tenant shall pay Landlord an amount equal to the proceeds Landlord would have received had Tenant maintained insurance on such items as required by this Lease).
Tenant’s Repair Obligations Tenant shall keep the Premises in good condition and repair, ordinary wear and tear excepted. Tenant’s repair obligations include, without limitation, repairs to: (1) floor covering and/or raised flooring; (2) interior partitions; (3) doors; (4) the interior side of demising walls; (5) electronic, phone and data cabling and related equipment (collectively, “Cable”) that is installed by or for the benefit of Tenant whether located in the Premises or in other portions of the Building; (6) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing, dishwashers, ice machines and similar facilities serving Tenant exclusively; (7) phone rooms used exclusively by Tenant; (8) Alterations (defined below) performed by contractors retained by Tenant, including related HVAC balancing; and (9) all of Tenant’s furnishings, trade fixtures, equipment and inventory. Prior to performing any such repair obligation, Tenant shall give written notice to Landlord describing the necessary maintenance or repair. Upon receipt of such notice, Landlord may elect either to perform any of the maintenance or repair obligations specified in such notice, or require that Tenant perform such obligations by using contractors approved by Landlord. All work that is Tenant’s responsibility hereunder shall be performed by Tenant (except as otherwise provided herein) at Tenant’s expense in accordance with the rules and procedures described in Section 9.C below. If Tenant fails to make any repairs to the Premises for more than 15 days after notice from Landlord (although notice shall not be required if there is an emergency), Landlord may, in addition to any other remedy available to Landlord, make the repairs, and Tenant shall pay to Landlord the reasonable cost of the repairs within 30 days after receipt of an invoice, together with an administrative charge in an amount equal to 15% of the cost of the repairs.
Landlord’s Repair Obligations If this Lease does not terminate with respect to the entire Premises under Section 12.1, and if the Taking includes a portion of the Premises, then this Lease shall automatically terminate as to the portion of the Premises taken as of the date the Condemning Authority takes possession of the portion taken and Landlord will, at its sole cost and expense, restore the remaining portion of the Premises to a complete architectural unit with all commercially reasonable diligence and speed and will reduce the Basic Rent for the period after the date the Condemning Authority takes possession of the portion of the Premises taken to a sum equal to the product of the Basic Rent provided for in this Lease multiplied by a fraction, the numerator of which is the rentable area of the Premises after the Taking and after Landlord restores the Premises to a complete architectural unit, and the denominator of which is the rentable area of the Premises prior to the Taking. Landlord will also equitably adjust Tenant's Share of Expenses Percentage for the same period, subject to Section 3.7, to account for the reduction in the rentable area of the Premises or the Building resulting from the Taking. Tenant's obligation to pay Basic Rent and Tenant's Share of Expenses will xxxxx on a proportionate basis with respect to that portion of the Premises remaining after the Taking that Tenant is unable to use during Landlord's restoration for the period of time that Tenant is unable to use such portion of the Premises.
Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.
Collection Costs In addition, the Issuer will pay the costs of collection, including all amounts owed to the Indenture Trustee under Section 6.7.
Termination Costs Concurrently with the exchange of final reports pursuant to Articles 4.2 and 5.2, PHS shall submit to the Collaborator for payment a statement of all costs incurred prior to the date of termination and for all reasonable termination costs including the cost of returning Collaborator property or removal of abandoned property, for which Collaborator shall be responsible.
Relocation Costs If relocation occurs after the Commencement Date, then Landlord shall pay Tenant's reasonable third-party costs of moving Tenant's furnishings, telephone and computer wiring, and other property to the Substitute Premises, and reasonable printing costs associated with the change of address.
Litigation Costs If any legal action or other proceeding is brought for the enforcement of this Agreement or to remedy its breach, the prevailing party in such action or proceeding shall be entitled to recover its actual attorney's fees and other costs incurred in the action or proceeding, in addition to such other relief to which it may be entitled.
Indemnification Costs and Expenses (a) Borrower agrees to indemnify and hold harmless Lender and each manager, partner, director, officer, employee, agent, attorney and affiliate thereof (each such person, an “Indemnified Person”) from and against any and all Indemnified Liabilities; provided, that (i) no Credit Party shall have any obligation to any Indemnified Person hereunder with respect to any Indemnified Liabilities (x) to the extent such Indemnified Liabilities arise from the gross negligence, bad faith or willful misconduct of that Indemnified Person, in each case, as determined by a final, non-appealable judgment of a court of competent jurisdiction or (y) to the extent such Indemnified Liabilities resulted solely from disputes between or among Indemnified Persons, and (ii) no Credit Party shall be liable for any settlement of any claim or proceeding effected by any Indemnified Person without the prior written consent of such Credit Party (which consent shall not be unreasonably withheld or delayed), but if settled with such consent or if there shall be a final judgment against an Indemnified Person, each of the Credit Parties shall indemnify and hold harmless such Indemnified Person from and against any loss or liability by reason of such settlement or judgment in the manner set forth in this Agreement.
Collection Costs and Attorneys’ Fees If a Party fails to perform an obligation or otherwise breaches one or more of the terms of this Agreement, the other Party may recover from the non-performing breaching Party all its costs (including actual attorneys’ and investigative fees) to enforce the terms of this Agreement.
