TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
Condition of the Contractor’s Property or Equipment The Contractor shall make the Property and/or equipment available to the Judicial Council, pursuant to the terms and conditions set forth in this Agreement. The Contractor shall immediately remedy any problem with the Property’s physical plant or equipment that impairs or diminishes the quality of the Program. The Contractor shall ensure the appropriate hot water, heating, and ventilation is provided at the Property during the Program, inclusive in the prices set forth herein.
Compensation for default by the Concessionaire Subject to the provisions of Clause 35.6, in the event of the Concessionaire being in material default or breach of this Agreement, it shall pay to the Authority by way of compensation, all direct costs suffered or incurred by the Authority as a consequence of such material default or breach, within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no compensation shall be payable under this Clause 35.1 for any material breach or default in respect of which Damages are expressly specified and payable under this Agreement.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Termination by the Customer The Customer may terminate this Agreement by providing a written notice of termination to the Transfer Agent, specifying the date as of which this Agreement will terminate, which may be any date, including the date such written notice is provided, provided the circumstances described below giving rise to the termination right are continuing at the time of the Transfer Agent’s receipt of such written notice, if as a result of an Event Beyond Reasonable Control:
Maintenance by the Manager Throughout the Term the Manager will inspect, maintain, repair and replace elements of the Residence in order to keep the Residence in a good condition and state of repair, complying with health, safety and fire standards required by law. This includes, but is not limited to, inspecting and testing fire safety equipment, major appliances, electrical, bathroom fixtures and plumbing.
Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.
No Warranty Regarding Goods or Services as Applicable We are not responsible for the quality, safety, legality, or any other aspect of any goods or services you purchase with the Card. Arbitration Any claim, dispute, or controversy (“Claim”) arising out of or relating in any way to: i) this Agreement; ii) the Card; iii) your acquisition of the Card; iv) your use of the Card; v) the amount of available funds in the Card Account; vi) advertisements, promotions or oral or written statements related to the Card, as well as goods or services purchased with the Card; vii) the benefits and services related to the Card; or viii) transactions on the Card, no matter how described, pleaded or styled, shall be FINALLY and EXCLUSIVELY resolved by binding individual arbitration conducted by the American Arbitration Association (“AAA”) under its Consumer Arbitration Rules. This arbitration agreement is made pursuant to a transaction involving interstate commerce, and shall be governed by the Federal Arbitration Act (9 U.S.C. 1-16). We will pay the initial filing fee to commence arbitration and any arbitration hearing that you attend shall take place in the federal judicial district of your residence. ARBITRATION OF YOUR CLAIM IS MANDATORY AND BINDING. NEITHER PARTY WILL HAVE THE RIGHT TO LITIGATE THAT CLAIM THROUGH A COURT. IN ARBITRATION, NEITHER PARTY WILL HAVE THE RIGHT TO A JURY TRIAL OR TO ENGAGE IN DISCOVERY, EXCEPT AS PROVIDED FOR IN THE AAA CODE OF PROCEDURE. For a copy of the procedures, to file a Claim or for other information about this organization, contact it at: AAA, 000 Xxxxxxx Xxxxxx, Xxx Xxxx, XX 00000, or at xxx.xxx.xxx. All determinations as to the scope, interpretation, enforceability and validity of this Agreement shall be made final exclusively by the arbitrator, which award shall be binding and final. Judgment on the arbitration award may be entered in any court having jurisdiction. NO CLASS ACTION, OR OTHER REPRESENTATIVE ACTION OR PRIVATE ATTORNEY GENERAL ACTION OR JOINDER OR CONSOLIDATION OF ANY CLAIM WITH A CLAIM OF ANOTHER PERSON OR CLASS OF CLAIMANTS SHALL BE ALLOWABLE. This arbitration provision shall survive: i) the termination of the Agreement; ii) the bankruptcy of any party; iii) any transfer, sale or assignment of the Card, or any amounts owed on the Card, to any other person or entity; or iv) expiration of the Card. If any portion of this arbitration provision is deemed invalid or unenforceable, the remaining portions shall remain in force. IF YOU DO NOT AGREE TO THE TERMS OF THIS ARBITRATION AGREEMENT, DO NOT ACTIVATE OR USE THE CARD. CALL 0-000-000-0000 TO CANCEL THE CARD AND MAKE ALTERNATE ARRANGEMENTS TO RECEIVE THE FUNDS ASSOCIATED WITH THE CARD ACCOUNT.
Selection of Subcontractors Procurement of Materials and Leasing of Equipment: The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
