RESPONSE TO NOTIFICATION OF DEFICIENCIES. Procedures for review and correction of deficiencies following notification from County. The Plan must specify what actions will be taken and by whom.
RESPONSE TO NOTIFICATION OF DEFICIENCIES Sample Clauses
Related to RESPONSE TO NOTIFICATION OF DEFICIENCIES
Correction of Deficiencies The contractor must correct promptly any work of his/her own or his/her subcontractors found to be defective or not complying with the terms of the contract.
Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.
Renewal Notice; Notification of Changes Subject to governing law, XOOM can renew this Agreement with new or revised Terms. XOOM will send you written notice at least (30) days before the end of the Term. The notice will specify the date by which you must advise XOOM if you do not want to renew your Agreement. If you do not advise XOOM by the specified date, this Agreement will automatically renew at the fixed rate or variable rate then in effect in accordance with the notice. XOOM reserves the right, with fifteen (15) days’ notice, to amend this Agreement to adjust its service to accommodate any change in regulations, law, tariff or other change in procedure required by any third party that may affect XOOM’s ability to continue to serve you under this Agreement.
Response to Demand Letter Within 10 days after the receipt of the Demand Letter, Ensign Group shall either: (a) cure the breach to OIG’s satisfaction and pay the applicable Stipulated Penalties or (b) request a hearing before an HHS administrative law judge (ALJ) to dispute OIG’s determination of noncompliance, pursuant to the agreed upon provisions set forth below in Section X.E. In the event Ensign Group elects to request an ALJ hearing, the Stipulated Penalties shall continue to accrue until Ensign Group cures, to OIG’s satisfaction, the alleged breach in dispute. Failure to respond to the Demand Letter in one of these two manners within the allowed time period shall be considered a material breach of this CIA and shall be grounds for exclusion under Section X.D.
Notification of Delay The Design Professional shall immediately notify the City in writing if Design Professional experiences or anticipates experiencing a delay in performing the Professional Services within the time frames set forth in the Task Order. The written notice shall include an explanation of the cause for, and a reasonable estimate of the length of, the delay. If in the opinion of the City, the delay affects a material part of the Task, the City may exercise its rights under Sections 2.5-2.7 of this Agreement.
BREACH DISCOVERY AND NOTIFICATION 23 1. Following the discovery of a Breach of Unsecured PHI, CONTRACTOR shall notify 24 COUNTY of such Breach, however both parties agree to a delay in the notification if so advised by a 25 law enforcement official pursuant to 45 CFR § 164.412.
Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.
Notification of Default (a) Each Obligor shall notify the Agent of any Default (and the steps, if any, being taken to remedy it) promptly upon becoming aware of its occurrence (unless that Obligor is aware that a notification has already been provided by another Obligor).
Stipulated Penalties for Failure to Comply with Certain Obligations As a contractual remedy, Xxxxxx and OIG hereby agree that failure to comply with certain obligations as set forth in this CIA may lead to the imposition of the following monetary penalties (hereinafter referred to as “Stipulated Penalties”) in accordance with the following provisions.
