Rights and Obligations of the Parties 5.2.1. The client is obliged to:
5.2.1.1. Check for an SMS at the moment of issuance of a card, by which means they will receive a pin code, or check the integrity of the envelope in which the pin code is given;
5.2.1.2. Regularly review and abide by card usage and security regulations developed by the Bank, and not allow disclosure of the card and/or pin-code to the third persons;
5.2.1.3. Reimburse those bank expenses which are related to additional service costs of VISA and Mastercard (if any);
5.2.1.4. Use the card to pay the Bank any commission fee related to card servicing (producing, renewal, including in the international stop-list, etc.) and processing card transactions consistent with the tariff established by the Bank and/or international payment systems;
5.2.1.5. Perform transactions on the card account only within the limits of the available balance. The Bank shall impose a penalty on an intentionally or erroneously overspent amount in excess of the available balance according to the tariff established by the Bank for each day of using the surcharge amount;
5.2.1.6. Promptly fill surcharged amount;
5.2.1.7. Promptly notify the Bank about loss of the card;
5.2.1.8. Shall process card payment transaction in the internet only through the web pages having secure payment certifications (web pages where MasterCard SecureCode or Verified by VISA logos are depicted, allowing for making payment with 3D security code). The bank shall bear no responsibility for the transactions of the client made at the web-pages having no secure payment certifications.
5.2.2. The client is authorized to:
5.2.2.1. At any time obtain information on transactions held at the card account and request statements reflecting such transactions. The client is authorized to become familiar with the transactions made at the card accounts in the internet banking and/or address JSC “Pasha Bank Georgia” telephone services center – contact center and/or any branch of the bank to obtain such information. Card transactions statements shall be issued in a form requested by the client in the timelines established by the bank, however no later than 2 (two) banking days after the request of the client has been made. The bank is entitled to establish the commission for issuing the transaction statement made for the card account.
5.2.2.2. Submit a justified claim on transactions performed on the card account consistent with clause 5.4 of the present agreement.
5.2.3. The client acknowledges that:
5.2.3.1. Cards produced by the Bank are equipped with contactless technology;
5.2.3.2. Throughout the territory of Georgia, contactless card transactions without a pin code are permitted to the amount of up to 100 (one hundred) GEL. The Bank does not bear responsibility and does not accept claims from clients for contactless transaction(s) performed with the card account of a client up to 100 GEL throughout Georgia (notwithstanding the number of such transactions performed with the card).
Rights and Obligations of Both Parties 7.1 Party A shall have the following rights and obligations: § to draw down and use the Loan according to this Contract; § if Party A repays the Loan before maturity date, it shall obtain prior written consent from Party B and shall compensate Party B against the losses for expected income and relevant expenses; § to bear all expenses incurred under this Contract; § it shall notify Party B at least 30 days in advance of any activities that would have a negative impact upon Party B’s ability to realize its rights such as joint operation, merger, restructuring, sale of material asset, etc. and obtain Party B’s written consent, otherwise, Party A is not allowed to carry out the afore mentioned activity before repayment of the Loan; § to notify Party B of any changes like location, contact address, business scope, legal representative and other commercial register items within 7 days after these changes; § it shall notify Party B immediately the occurrence of any event that will affect its normal operation or solvency under this contract, such as (but not restrain to) severe economic dispute, bankruptcy, financial deterioration etc; § In case of it winding up, dissolution, suspension of operation, revoke of business license, Party A should notify Party B of such events within 5 days after their occurrence and undertake to repay the principal and interest immediately. § Others as agreed.
7.2 Party B shall have the following rights and obligations: § to require Party A to provide all materials related to the Loan; § to deduct the principal, interest, compound interest, penalty interest and other due expenses relating to the Loan under this Contract directly from Party B’s account in accordance with the provisions of this Contract or relevant law; § in case of Party A’s evasion of Party B’s monitoring, default in payment for due principal or interest and other severe breach of the Contract, Party B is entitled to impose credit penalty against Party A, notify relevant departments or entities of such breach and put up payment demand notice on public media; § to provide loan to Party A in time according to the provisions of the Contract (except for the delays due to Party A’s reason); § to keep confidential of the information and materials provided by Party A..
Rights and Obligations of Party B 8.1 Party B is entitled to use the Leased Units in accordance with the Contract. Party B may set a notable mark on the exit of elevators of the floor of leasing pursuant to the xxxevant management regulations of the Corporate Squares. The detailed conditions shall be discussed by both Parties.
8.2 Party B shall carry out the business activities in the Leased Units in compliance with laws, regulations and rules of the People's Republic of China and is prohibited to harm Party A's reputation through its activities.
8.3 Party B shall duly make the payments with respect to the rent, property management fee, electricity usage fee and any other charges it shall be responsible for.
8.4 Starting from the Commencement Date, Party B shall purchase insurance for the properties in the Leased Units, including property insurance and third party liability insurance. Otherwise, Party B and not Party A shall be solely responsible for all liabilities and losses.
8.5 Party B shall not alter the purpose of use of the Leased Units without consent in writing from Party A.
8.6 Party B shall not re-lend, sublease, and exchange the Leased Units, in whole or part, to third parties or allow third parties to use the Leased Units by other means, without consent in writing from Party A.
8.7 Party B shall not alter the locking and security system on the gate of the Leased Units without consent in writing from Party A or approval from related departments.
8.8 Party B shall not alter or move the equipment for usage of water and electricity and shall not enlarge the capacities of central air conditioning, without consent in writing from Party A.
8.9 Party B shall take necessary actions to prevent the Leased Units from fires accident or man-made damage. Party B shall immediately notify to Party A with respect to any damage of the Leased Units. Party B shall restore the damaged parts of the Leased Units to their former condition within one month upon receipt of Party A's notice, provided that the damages resulted from negligence by Party B and its employees. If Party B fails to do so timely, Party A has the right to repair the damaged parts. All the expenses thus incurred shall be borne by Party B.
8.10 Party B is entitled to require Party A repairing the Leased Units, and the public facilities and equipment, and repair such based on the original standards by itself if Party A fails to perform the obligation of repairing timely and affects the normal use of such. All the expenses thus incurred shall be borne by Party A. The equipment newly added or improved by Party B shall be repaired by Party B.
Rights and Obligations of Party A 0. Xxxxx A has the right to require Party B to keep in confidence relevant financial information and trade secrets relating to production and operation of Party A unless otherwise provided by laws and regulations.
2. Party A shall provide relevant financial information and information relating to production and operation as required by Party B and shall be responsible for the authenticity, integrity and validity of such information.
3. Party A undertakes that all settlements and deposits relating to the Loan shall be conducted through its accounts opened with Party B or Party B’s relevant branch.
4. Party A shall assist in and accept Party B’s inspection and supervision of its production, operation, financial activities and utilization of the Loan.
5. Party A shall utilize the Loan for the purpose as provided for hereunder.
6. Party A shall punctually repay the principal and interest in accordance with this Contract.
7. Party A or its investors shall not transfer any funds or assets in order to evade the indebtedness owed to Party B.
8. Party A shall give Party B a prior written notice for Party B’s consent if Party A intends to provide security for any third party during the term of this Contract and such security may affect Party A’s ability to make repayment under this Contract.
9. Party A shall promptly arrange for new security(ies) satisfactory to Party B where the Guarantor in respect of this Contract ceases or suspends production; its corporate registration is canceled, or business license revoked; it is bankrupt or dissolved; it is operating at a loss; or any other negative change has occurred, and such aforementioned incidents result in loss or partial loss of the Guarantor’s ability to secure the Loan, or where the mortgaged or pledged property(ies) for securing the Loan depreciate(s) or is (are) damaged or destroyed.
10. Party A shall promptly inform Party B of any relevant changes during the term of this Contract, including without limitation its business name, legal representative (or chief officer), registered office, business purpose or registered capital.
11. Where Party A intends to carry out activity(ies) during the term of this Contract which may have an impact on the realization of Party B’s rights hereunder, Party A shall give Party B a [30] banking days prior written notice for its consent to such intended activity(ies) and shall further take sufficient measures to safeguard the repayment of the indebtedness under this Contract and arrange for security in accordance with Party B’s instructions. The aforementioned activities shall include without limitation contracting, leasing, transformation to a stock company, forming an economic association with another enterprise, consolidation, merger, division, setting up a joint venture, application for suspension of production or for winding up or for bankruptcy.
12. Party A shall promptly inform Party B in writing, take sufficient measures to safeguard the repayment of the indebtedness under this Contract and arrange for security(ies) in accordance with Party B’s instructions if there has occurred to Party A incident(s) during the term of this Contract that may have substantially negative effects on Party B’s performance of its obligations hereunder. The aforementioned incidents shall include without limitation the following: Party A ceases or suspends production; its corporate registration is canceled, or business license revoked; its legal representative or high-ranking officers are involved in illegal activities; it is involved in litigation with a major impact; great difficulties arise in respect to its production or operation; or its financial standing deteriorates.
13. Party A shall bear all fees and expenses in connection with this Contract and the security(ies) for this Contract including without limitation fees and expenses in respect to legal services, insurance, evaluation, registration, storage, authentication and notarization.
Rights and Obligations of Limited Partners Section 8.1 Limitation of Liability 27 Section 8.2 Management of Business 27 Section 8.3 Outside Activities 27 Section 8.4 Return of Capital 27 Section 8.5 Rights of Limited Partners Relating to the Partnership 27
Finance Parties’ rights and obligations (a) The obligations of each Finance Party under the Finance Documents are several. Failure by a Finance Party to perform its obligations under the Finance Documents does not affect the obligations of any other Party under the Finance Documents. No Finance Party is responsible for the obligations of any other Finance Party under the Finance Documents.
(b) The rights of each Finance Party under or in connection with the Finance Documents are separate and independent rights and any debt arising under the Finance Documents to a Finance Party from an Obligor shall be a separate and independent debt.
(c) A Finance Party may, except as otherwise stated in the Finance Documents, separately enforce its rights under the Finance Documents.
Party B’s Rights and Obligations 9.2.1 Party B guarantees that it will use the Leased Unit properly according to the Agreement, be responsible for its own profits and losses and operate independently;
9.2.2 After being submitted to Party A for examination and approval, the Leased Unit shall be renovated at its own expense; The decoration of Leased Unit must abide by the codes, regulations and requirements on decoration formulated by Party A and the property company, and accept the supervision of Party A;
9.2.3 After the expiration of the lease term, if Party B needs to renew the agreement, it shall submit a written application to Party A three months before the expiration of the Agreement. After both parties reach an agreement on renewing the agreement, they shall renew the agreement 30 days before the expiration of the Agreement. Otherwise, Party B shall be deemed to have given up the priority to lease;
9.2.4 Party B shall pay rent, property management fee, water and electricity fee on time and in quantity, and pay relevant taxes and fees to the state and local government by itself. Party B shall guarantee legal operation during the lease term, and shall not be in arrears with employees’ wages; otherwise, all liabilities arising therefrom shall be borne by Party B itself;
9.2.5 During the lease term, Party B shall reasonably utilize, actively maintain, and repair the Leased Unit and the equipment and facilities in the Leased Unit to ensure the overall safety and normal operation of the Leased Unit, and all expenses arising from the repair and maintenance shall be borne by Party B;
9.2.6 Party B shall bear the fire safety responsibility of the Leased Unit. Party B shall not store or allow others to store inflammable, explosive, toxic and other dangerous goods in the Leased Unit. If a fire accident occurs in the Leased Unit, unless the national fire safety department proves that the cause of the accident has nothing to do with Party B, all its responsibilities shall be borne by Party B; In case of property and personnel casualties of Party A or others, Party B shall bear all compensation responsibilities;
9.2.7 Party B shall accept and cooperate with the unified management of Party A and the property management company, and abide by the property management regulations, codes and relevant unified charging standards of the Building;
9.2.8 During the lease term, Party B shall insure its own property and personnel in the Leased Unit and go through the insurance formalities by itself. Party B shall be responsible for the safety of personnel and property in the Leased Unit, and shall be responsible for the safety of ancillary facilities, personnel and articles in the Leased Unit. In case of loss or damage of articles, and injury or death of people in the Leased Unit, all the consequences and responsibilities shall be borne by Party B independently;
9.2.9 The procedures such as industrial and commercial procedures, and tax registration procedures, as well as the licenses such as fire protection license or other business license required by Party B shall be handled by Party B itself, and the expenses shall be borne by Party B. The consequences and responsibilities caused by incomplete procedures or licenses shall be borne by Party B itself;
9.2.10 Without the prior written consent of Party A, it is not allowed to use the name of Party A or the Building or the name of 「Xiangjiang Financial Center」 and its related trade names and trademarks for social activities, publicity, commodity packaging, printing, advertising, making badges, etc., but it does not include the use of 「Xiangjiang Financial Center」 as the address of its business or commodity packaging;
9.2.11 Party B shall not destroy, damage or smear any part of the Building, or any decorations in public areas, stairs, elevators and escalators, and shall not smear, deface, post advertisements around the Leased Unit, set up stalls, or do other acts that hinder the overall cleanliness. Party B shall promptly dispose of any packing, cartons, garbage or other obstacles of any kind or nature left or untreated in the public areas, so as not to affect the hygiene and cleanliness of the public areas;
9.2.12 Without Party A’s consent, Party B can only register one business entity in the Leased Unit. If Party B registers a business entity in the Leased Unit, Party B and the business entity registered by Party B guarantee that they shall jointly perform all obligations of this Agreement; If Party B needs to transfer Party B’s rights and obligations in this Agreement to the newly registered business entity, it shall issue copies of business license and tax registration certificate with official seal and issue a written notice to Party A on the establishment date of the newly registered business entity, and Party A, Party B and the newly registered business entity can sign the rights and obligations transfer agreement only on the premise that Party B and its guarantor guarantee to bear joint and several guarantee liabilities for Party B’s newly registered business entity to fulfill all obligations under this Agreement;
9.2.13 Accept and abide by the management rules and regulations of the Building.
Parties' Rights and Obligations If during the Term there is any Condemnation of all or any part of the Leased Property or any interest in this Lease, the rights and obligations of Lessor and Lessee shall be determined by this Article 15.
Independent Nature of Rights and Obligations Nothing contained herein, and no action taken by any party pursuant hereto, shall be deemed to constitute Investor and the Sponsor as, and the Sponsor acknowledges that Investor and the Sponsor do not so constitute, a partnership, an association, a joint venture or any other kind of entity, or create a presumption that Investor and the Sponsor are in any way acting in concert or as a group with respect to such obligations or the transactions contemplated by this Agreement or any matters, and the Sponsor acknowledges that Investor and the Sponsor are not acting in concert or as a group, and the Sponsor shall not assert any such claim, with respect to such obligations or the transactions contemplated by this Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
