Monthly Fee 2.1 The monthly fee is € . The monthly fee includes value-added tax at the statutory rate, which is currently 19%. In the event of changes to the statutory value-added tax payable and/or if any additional taxes/levies have to be paid, the fee specified above may be recalculated accordingly.
PAYMENT TERMS/PRE-PAYMENT/QUANTITY DISOUNTS If discounts for accelerated payment, pre-payment, progress payment, or quantity discounts are offered, they must be clearly indicated in the Contractor’s submission prior to contract award. The applicability or acceptance of these terms is at the discretion of the Customer.
Gross Settlement Amount Except as otherwise provided by Paragraph 8 below, Defendant promises to pay $290,000.00 and no more as the Gross Settlement Amount and to separately pay any and all employer payroll taxes owed on the Wage Portions of the Individual Class Payments. Defendant has no obligation to pay the Gross Settlement Amount (or any payroll taxes) prior to the deadline stated in Paragraph 4.3 of this Agreement. The Administrator will disburse the entire Gross Settlement Amount without asking or requiring Participating Class Members or Aggrieved Employees to submit any claim as a condition of payment. None of the Gross Settlement Amount will revert to Defendant.
Funding of Gross Settlement Amount Defendant shall fully fund the Gross Settlement Amount, and also fund the amounts necessary to fully pay Defendant’s share of payroll taxes by transmitting the funds to the Administrator no later than 14 days after the Effective Date.
Monthly Fees ACS will xxxx Customer each month during the term of this Agreement based on number of "Actions" which occurred during the prior month. The definition of "Actions" and fees for each Action will be documented in each Task Order. Customer shall cause ACS to be paid the foregoing fees on a monthly basis within thirty (30) days of ACS' delivery of an invoice for the preceding month's Actions.
Billing, Payment, Milestones and Financial Security
Minimum Payment Due Your Minimum Payment Due is listed on your Statement and equals the lesser of: • the amount of your New Balance, or • the greater of: • $30, or • 3% of the amount you owe, or • the sum of Finance Charges accrued since the last Billing Cycle (including Interest Charges and Transaction Fees), plus any Penalty Fees, Annual Fees (if applicable), and one-time fees that have been posted to your Account, plus 1% of the amount you owe. Making only the Minimum Payment Due will increase the amount of interest you pay and the time it takes to repay your balance.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Payments from the Gross Settlement Amount The Administrator will make and deduct the following payments from the Gross Settlement Amount, in the amounts specified by the Court in the Final Approval:
Rent Payment Tenant shall pay the Base Rent for the Premises and any additional rent provided herein without deduction or offset. Rent for any partial month during the lease term shall be prorated to reflect the number of days during the month that Tenant occupies the Premises. Additional rent means amounts determined under Section 19 of this Lease and any other sums payable by Tenant to Landlord under this Lease. Rent not paid when due shall bear interest at the rate of one-and-one-half percent per month until paid. Landlord may at its option impose a late charge of $.05 for each $1 of rent for rent payments made more than 10 days late in lieu of interest for the first month of delinquency, without waiving any other remedies available for default. Failure to impose a late charge shall not be a waiver of Landlord’s rights hereunder.
