RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
Licensed Technology (a) LICENSOR is not aware of any interference, infringement, misappropriation, or other conflict with any intellectual property rights of third parties, and LICENSOR has never received any charge, complaint, claim, demand, or notice alleging any such interference, infringement, misappropriation, or violation (including any claim that LICENSOR must license or refrain from using any intellectual property rights of any third party). To the knowledge of LICENSOR, no third party has interfered with, infringed upon, misappropriated, or otherwise come into conflict with any of the LICENSED TECHNOLOGY. (b) Exhibit A identifies each patent or registration which has been issued to LICENSOR with respect to any of the LICENSED TECHNOLOGY and identifies each pending patent application or application for registration which LICENSOR has made with respect to any of the LICENSED TECHNOLOGY. LICENSEE acknowledges that LICENSOR has previously made available to LICENSEE correct and complete copies of all such patents, registrations and applications (as amended to-date) in LICENSOR’s possession and has made available to LICENSEE correct and complete copies of all other written documentation in LICENSOR’s possession evidencing ownership and prosecution (if applicable) of each such item. (c) Exhibit A identifies each item of LICENSED TECHNOLOGY that is assigned to LICENSOR or that LICENSOR uses pursuant to license, sublicense, agreement, or permission. LICENSOR has made available to LICENSEE correct and complete copies of all such licenses, sublicenses, agreements, patent prosecution files and permissions (as amended to-date) in LICENSOR’s possession. With respect to each item of LICENSED TECHNOLOGY required to be identified in Exhibit A and to the knowledge of LICENSOR: (i) the license, sublicense, agreement, or permission covering the item is legal, valid, binding, enforceable, and in full force and effect; (ii) the license, sublicense, agreement, or permission will continue to be legal, valid, binding, enforceable, and in full force and effect on identical terms following the consummation of the transactions contemplated hereby; (iii) no Party to the license, sublicense, agreement, or permission is in breach or default, and no event has occurred which with notice or lapse of time would constitute a breach or default or permit termination, modification, or acceleration thereunder; (iv) no party to the license, sublicense, agreement, or permission has repudiated any provision thereof; (v) the underlying item of LICENSED TECHNOLOGY is not subject to any outstanding lien or encumbrance, injunction, judgment, order, decree, ruling, or charge; (vi) no action, suit, proceeding, hearing, investigation, charge, complaint, claim, or demand is pending or is threatened which challenges the legality, validity, or enforceability of the underlying item of LICENSED TECHNOLOGY; and (vii) except as provided in Exhibit A, LICENSOR has not granted any license or similar right to the LICENSED TECHNOLOGY within the GENERAL FIELD or PARTHENOGENESIS FIELD.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
Third Party Technology The Company makes use of third party technology to collect information required for traffic measurement, research, and analytics. Use of third party technology entails data collection. We therefore would like to inform clients the Company enables third parties to place or read cookies located on the browsers of users entering the Company’s domain. Said third parties may also use web beacons to collect information through advertising located on the Company’s web site. Please note that you may change your browser settings to refuse or disable Local Shared Objects and similar technologies; however, by doing so you may be disabling some of the functionality of Company’s services.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
Manufacturing Technology Transfer Upon AbbVie’s written request with respect to a given Collaboration CAR-T Product and Licensed Product, Caribou shall effect a full transfer to AbbVie or its designee (which designee may be an Affiliate or a Third Party Provider) of all Materials and Know-How Controlled by Caribou relating to the then-current process for the Manufacture of such Collaboration CAR-T Product and any corresponding Licensed Products (each, a “Manufacturing Process”). Caribou shall provide, shall cause its Affiliates to provide, and shall use Commercially Reasonable Efforts to assist AbbVie in causing all Third Party Providers to provide, all reasonable assistance requested by AbbVie to enable AbbVie (or its Affiliate or designated Third Party Provider, as applicable) to implement each Manufacturing Process at the facilities designated by AbbVie. If requested by AbbVie, such assistance shall include facilitating the entering into of agreements with applicable Third Party suppliers relating to such Collaboration CAR-T Product and any corresponding Licensed Products. Without limitation of the foregoing, in connection with the Manufacturing Process and related transfer: (a) Caribou shall, and shall cause its Affiliates to, make available to AbbVie (or its Affiliate or designated Third Party Provider, as applicable), and shall use Commercially Reasonable Efforts to assist AbbVie in causing all Third Party Providers to make available to AbbVie, from time to time as AbbVie may request, all Materials and Manufacturing-related Know-How Controlled by Caribou relating to each Manufacturing Process, including methods, reagents and processes and testing/characterization Know-How, and all documentation constituting material support, performance advice, shop practice, standard operating procedures, specifications as to Materials to be used, and control methods, that are necessary or reasonably useful to enable AbbVie (or its Affiliate or designated Third Party manufacturer, as applicable) to use and practice such Manufacturing Process; (b) Caribou shall cause all appropriate employees and representatives of Caribou and its Affiliates, and shall use Commercially Reasonable Efforts to assist AbbVie in causing all appropriate employees and representatives of Third Party Providers, to meet with employees or representatives of AbbVie (or its Affiliate or designated Third Party Provider, as applicable) at the applicable manufacturing facility at mutually convenient times to assist with the working up and use of each Manufacturing Process and with the training of the personnel of AbbVie (or its Affiliate or designated Third Party Provider, as applicable) to the extent necessary or reasonably useful to enable AbbVie (or its Affiliate or designated Third Party Provider, as applicable) to use and practice such Manufacturing Process; (c) Without limiting the generality of this Section 4.4.2, Caribou shall cause all appropriate analytical and quality control laboratory employees and representatives of Caribou and its Affiliates, and shall use Commercially Reasonable Efforts to assist AbbVie in causing all appropriate analytical and quality control laboratory employees and representatives of Third Party Providers, to meet with employees or representatives of AbbVie (or its Affiliate or designated Third Party Provider, as applicable) at the applicable manufacturing facility and make available all necessary equipment, at mutually convenient times, to support and execute the provision of all applicable analytical methods and the validation thereof (including all applicable Know-How, Information and Materials Controlled by Caribou, and sufficient supplies of all primary and other reference standards); (d) Caribou shall, and shall cause its Affiliates to, take such steps, and shall use Commercially Reasonable Efforts to assist AbbVie in causing Third Party Providers take such steps, as are necessary or reasonably useful to assist AbbVie (or its Affiliate or designated Third Party Provider, as applicable) in obtaining any necessary licenses, permits or approvals from Regulatory Authorities with respect to the Manufacture of the applicable Collaboration CAR-T Products and corresponding Licensed Products at the applicable facilities; and (e) Caribou shall, and shall cause its Affiliates to, provide, and shall use Commercially Reasonable Efforts to assist AbbVie in causing Third Party Providers to provide, such other assistance as AbbVie (or its Affiliate or designated Third Party Provider, as applicable) may reasonably request to enable AbbVie (or its Affiliate or designated Third Party Provider, as applicable) to use and practice each Manufacturing Process and otherwise to Manufacture the applicable Collaboration CAR-T Products and corresponding Licensed Products.
Licensed Products Lessee will obtain no title to Licensed Products which will at all times remain the property of the owner of the Licensed Products. A license from the owner may be required and it is Lessee's responsibility to obtain any required license before the use of the Licensed Products. Lessee agrees to treat the Licensed Products as confidential information of the owner, to observe all copyright restrictions, and not to reproduce or sell the Licensed Products.
Third Party Components The Products and Services may contain third party components (including open source software) subject to separate license agreements. To the limited extent a third party license expressly supersedes this XXXX, such third party license governs Customer’s use of that third party component.
Licensed Product The term “Licensed Product” shall mean any product (a) the manufacture, use, importation, sale or offer for sale of which would, in the absence of the license granted by this Agreement, infringe a Valid Claim of any of the Licensed Patent Rights, or (b) that is comprised of, utilizes or incorporates Licensed Biological Materials, or (c) that is discovered, developed or made using a Licensed Process.
