Other Products If you ask, we will provide you with information on any other home equity products we offer.
MERCURY ADDED CONSUMER PRODUCTS Contractor agrees that it will not sell or distribute fever thermometers containing mercury or any products containing elemental mercury for any purpose under this Contract.
Products Products available under this Contract are limited to Software, including Software as a Service, products and related products as specified in Appendix C, Pricing Index. Vendor may incorporate changes to their product offering; however, any changes must be within the scope of products awarded based on the posting described in Section 1.B above. Vendor may not add a manufacturer’s product line which was not included in the Vendor’s response to the solicitation described in Section 1.B above.
Other Products and Services As our customer, you have access to a suite of financial products and services availed by ourselves, our affiliates and strategic partners designed to help you address and achieve your financial needs and goals. You agree that you can obtain information about such Products and Services via our website xxx.xxxxxxxx.xxx.xx and you further agree that we can from time to time communicate information in relation to such Products or Services to you specifically or generally to all cardmembers via such communication mode as we consider appropriate.
Existing Products Except as set forth below, Contractor shall retain all rights, title and interest in Existing Products.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
New Products You agree to comply with NASD Notice to Members 5-26 recommending best practices for reviewing new products.
Recycled Products The Contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. References: 42 U.S.C. 6962, 40 CFR Part 247, Executive Order 12873 (More than $10,000)
Software Products Save as otherwise set forth in the Agreement, the right to use any Software Product is personal to the Licensee, for its own internal use, and is non-transferable, except with the Licensor’s prior written consent, in which case the Licensee shall cause the assignee or sub-licensee to agree to the terms of this Software License.
Borrower Products Except as described on Schedule 5.11, no Intellectual Property owned by Borrower or Borrower Product has been or is subject to any actual or, to the knowledge of Borrower, threatened litigation, proceeding (including any proceeding in the United States Patent and Trademark Office or any corresponding foreign office or agency) or outstanding decree, order, judgment, settlement agreement or stipulation that restricts in any manner Borrower’s use, transfer or licensing thereof or that may affect the validity, use or enforceability thereof. There is no decree, order, judgment, agreement, stipulation, arbitral award or other provision entered into in connection with any litigation or proceeding that obligates Borrower to grant licenses or ownership interest in any future Intellectual Property related to the operation or conduct of the business of Borrower or Borrower Products. Borrower has not received any written notice or claim, or, to the knowledge of Borrower, oral notice or claim, challenging or questioning Borrower’s ownership in any Intellectual Property (or written notice of any claim challenging or questioning the ownership in any licensed Intellectual Property of the owner thereof) or suggesting that any third party has any claim of legal or beneficial ownership with respect thereto nor, to Borrower’s knowledge, is there a reasonable basis for any such claim. Neither Borrower’s use of its Intellectual Property nor the production and sale of Borrower Products infringes the Intellectual Property or other rights of others.
