Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Note for Victorian customers In Victoria, a retailer must obtain a customer’s ‘explicit informed consent’ to base the customer’s bill on an estimation, unless the meter cannot be read or the metering data is not obtained.
Applicable for Home Care Nurses: A full-time nurse reporting back to work upon request after completing the daily client assignment and following completion of a seven and three-quarter (7.75) hour shift but before commencement of their next scheduled shift shall be paid at overtime rates of pay with a guaranteed minimum of three (3) hours at overtime rates. If the extra time worked under this subsection commences within less than three (3) hours before the start of a shift, the guaranteed minimum of overtime pay will not apply. In such cases, the nurse will be paid at overtime rates from the time the nurse starts to work to the beginning of their shift.
COVID-19 Vaccine Passports Pursuant to Texas Health and Safety Code, Section 161.0085(c), Contractor certifies that it does not require its customers to provide any documentation certifying the customer’s COVID-19 vaccination or post-transmission recovery on entry to, to gain access to, or to receive service from the Contractor’s business. Contractor acknowledges that such a vaccine or recovery requirement would make Contractor ineligible for a state-funded contract.
Multi-year Planning Targets Schedule A may reflect an allocation for the first Funding Year of this Agreement as well as planning targets for up to two additional years, consistent with the term of this Agreement. In such an event, the HSP acknowledges that if it is provided with planning targets, these targets:
a. are targets only,
b. are provided solely for the purposes of planning,
c. are subject to confirmation, and
d. may be changed at the discretion of the Funder in consultation with the HSP. The HSP will proactively manage the risks associated with multi-year planning and the potential changes to the planning targets; and the Funder agrees that it will communicate any changes to the planning targets as soon as reasonably possible.
Certification Regarding Lobbying Applicable to Grants Subgrants, Cooperative Agreements, and Contracts Exceeding $100,000 in Federal Funds Submission of this certification is a prerequisite for making or entering into this transaction and is imposed by section 1352, Title 31, U.S. Code. This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure. The undersigned certifies, to the best of his or her knowledge and belief, that: (1) No Federal appropriated funds have been paid or will be paid by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of congress, or an employee of a Member of Congress in connection with the awarding of a Federal contract, the making of a Federal grant, the making of a Federal loan, the entering into a cooperative agreement, and the extension, continuation, renewal, amendment, or modification of a Federal contract, grant, loan, or cooperative agreement.
How Are Contributions to a Xxxx XXX Reported for Federal Tax Purposes You must file Form 5329 with the IRS to report and remit any penalties or excise taxes. In addition, certain contribution and distribution information must be reported to the IRS on Form 8606 (as an attachment to your federal income tax return.)
Vendor Encouraging Members to bypass TIPS agreement Encouraging entities to purchase directly from the Vendor or through another agreement, when the Member has requested using the TIPS cooperative Agreement or price, and thereby bypassing the TIPS Agreement is a violation of the terms and conditions of this Agreement and will result in removal of the Vendor from the TIPS Program.
