Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.
Advance Deposits All prepaid rentals, room rental deposits, and all other deposits for advance registration, banquets or future services to be provided on and after the Closing Date shall be credited to Buyer.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Conditions for Advance and Conditions to Closing Section 7.1.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
INVOICING REQUIREMENTS A. Upon acceptance of work by the Service Coordinator, the Contractor shall submit the invoice (and supporting documents where applicable) to the appropriate County department per the issued Delivery Order within thirty (30) calendar days of the acceptance. At minimum, all invoice shall contain the following information: • Correct Delivery Order number • Description of work performed to include the manufacturer name, original make and model number(s) of parts and equipment installed. • Start and ending date of the work • Location of the work • Total labor categorized per the Bid Response Form and rounded to the nearest (30) minutes • Itemized list of materials used according to the original manufacturer’s part name and part number. ▪ Unit price and quantity shall be provided on the invoice for each part • Applicable sales tax for materials purchased should be listed separately • Markdown/mark-ups for material shall be listed as a line item on the invoice. • Approved shipping charges shall be listed separately • Permit and special equipment rental cost for reimbursement (if applicable) • Invoice total
B. Proof of purchase for all reimbursable expense must be submitted with the invoice showing the actual cost for all reimbursable expenses by the County, including but not limited to, parts, shipping, sales tax, permits, specialty equipment rentals, etc. The Contractor shall provide a separate service ticket for each work day as verification of actual labor spent on the project daily.
C. The Contractor shall not combine charges for multiple Delivery Orders on the same invoice. Each Delivery Order must be invoiced separately.
D. The County will review invoices for the required information. The County will have the authority to reject invoices based on improper invoice format and lack of supporting documents.
E. The Contractor shall not invoice the County for any work not accepted by the County. Should the County received such invoices, they will be rejected.
F. Unless otherwise authorized by the corresponding department in writing, delivery of invoices and back-up documentation via e-mail and/or fax is not allowed under this contract. All invoices shall be mailed or hand delivered to the appropriate Department as referenced as the “Invoice To:” location and on the Delivery Order.
G. The Contractor shall submit monthly statements of unpaid invoices to each department ordering services under this contract. The Contractor shall not combine statements for different Departments utilizing this contract. • Statement date • Invoice numbers • Invoice dates • Invoice total or unpaid balance if different from invoice total • Delivery order number corresponding to each invoice listed • Balance carry forward • Cumulative outstanding balance Statements shall be sent to the corresponding Department’s, fiscal department, and the Contract Administrator by the 15th day of each month for service performed in the prior month and upon request by the County.
Expectations Regarding Advance Notices Within ten (10) days after the commencement of each calendar quarter occurring subsequent to the commencement of the Commitment Period, the Company must notify the Investor, in writing, as to its reasonable expectations as to the dollar amount it intends to raise during such calendar quarter, if any, through the issuance of Advance Notices. Such notification shall constitute only the Company's good faith estimate and shall in no way obligate the Company to raise such amount, or any amount, or otherwise limit its ability to deliver Advance Notices. The failure by the Company to comply with this provision can be cured by the Company's notifying the Investor, in writing, at any time as to its reasonable expectations with respect to the current calendar quarter.
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day.
B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx.
C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to
D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client.
E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time.
F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx.
G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
