Schedule Liquidated Damages for Interim Completion Sample Clauses

Schedule Liquidated Damages for Interim Completion. (a) Owner and Contractor acknowledge and agree that any failure to achieve Interim Completion by the Guaranteed Interim Completion Date will directly cause substantial damage to Owner, which damage cannot be ascertained with reasonable certainty. Accordingly, if Contractor shall fail to achieve Interim Completion by the Guaranteed Interim Completion Date, subject to Section 11.07(c), it shall pay to Owner, as liquidated damages, the following amounts (collectively, the “Schedule Liquidated Damages”): For each day (or portion thereof) that Interim Completion is delayed beyond the Guaranteed Interim Completion Date, commencing with the first day following the Guaranteed Interim Completion Date through and including the Interim Completion Date: Day 1 through 30 $ * ****/day Day 31 through 60 $ * ****/day Day 61 and beyond $ * ****/day
Sample 1
AutoNDA by SimpleDocs

Related to Schedule Liquidated Damages for Interim Completion

  • Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.

  • Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.

  • Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Compensation for Buy-In on Failure to Timely Deliver Conversion Shares Upon Conversion In addition to any other rights available to the Holder, if the Company fails for any reason to deliver to the Holder such Conversion Shares by the Share Delivery Date pursuant to Section 4(c)(ii), and if after such Share Delivery Date the Holder is required by its brokerage firm to purchase (in an open market transaction or otherwise), or the Holder’s brokerage firm otherwise purchases, shares of Common Stock to deliver in satisfaction of a sale by the Holder of the Conversion Shares which the Holder was entitled to receive upon the conversion relating to such Share Delivery Date (a “Buy-In”), then the Company shall (A) pay in cash to the Holder (in addition to any other remedies available to or elected by the Holder) the amount, if any, by which (x) the Holder’s total purchase price (including any brokerage commissions) for the Common Stock so purchased exceeds (y) the product of (1) the aggregate number of shares of Common Stock that the Holder was entitled to receive from the conversion at issue multiplied by (2) the actual sale price at which the sell order giving rise to such purchase obligation was executed (including any brokerage commissions) and (B) at the option of the Holder, either reissue (if surrendered) this Debenture in a principal amount equal to the principal amount of the attempted conversion (in which case such conversion shall be deemed rescinded) or deliver to the Holder the number of shares of Common Stock that would have been issued if the Company had timely complied with its delivery requirements under Section 4(c)(ii). For example, if the Holder purchases Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted conversion of this Debenture with respect to which the actual sale price of the Conversion Shares (including any brokerage commissions) giving rise to such purchase obligation was a total of $10,000 under clause (A) of the immediately preceding sentence, the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Holder’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver Conversion Shares upon conversion of this Debenture as required pursuant to the terms hereof.

  • Compensation for Buy-In on Failure to Timely Deliver Warrant Shares Upon Exercise In addition to any other rights available to the Holder, if the Company fails to cause the Transfer Agent to transmit to the Holder the Warrant Shares in accordance with the provisions of Section 2(d)(i) above pursuant to an exercise on or before the Warrant Share Delivery Date, and if after such date the Holder is required by its broker to purchase (in an open market transaction or otherwise) or the Holder’s brokerage firm otherwise purchases, shares of Common Stock to deliver in satisfaction of a sale by the Holder of the Warrant Shares which the Holder anticipated receiving upon such exercise (a “Buy-In”), then the Company shall (A) pay in cash to the Holder the amount, if any, by which (x) the Holder’s total purchase price (including brokerage commissions, if any) for the shares of Common Stock so purchased exceeds (y) the amount obtained by multiplying (1) the number of Warrant Shares that the Company was required to deliver to the Holder in connection with the exercise at issue times (2) the price at which the sell order giving rise to such purchase obligation was executed, and (B) at the option of the Holder, either reinstate the portion of the Warrant and equivalent number of Warrant Shares for which such exercise was not honored (in which case such exercise shall be deemed rescinded) or deliver to the Holder the number of shares of Common Stock that would have been issued had the Company timely complied with its exercise and delivery obligations hereunder. For example, if the Holder purchases Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted exercise of shares of Common Stock with an aggregate sale price giving rise to such purchase obligation of $10,000, under clause (A) of the immediately preceding sentence the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Xxxxxx’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver shares of Common Stock upon exercise of the Warrant as required pursuant to the terms hereof.

  • Company’s Failure to Timely Deliver Securities If the Company shall fail, for any reason or for no reason, on or prior to the Share Delivery Date, if the Transfer Agent is not participating in FAST or such shares of Common Stock may not be issued without legends under the Securities Act, to issue and deliver to the Holder (or its designee) a certificate for the number of Warrant Shares to which the Holder is entitled and register such Warrant Shares on the Company’s share register or, if the Transfer Agent is participating in FAST and such shares of Common Stock may not be issued without legends under the Securities Act, to credit the balance account of the Holder or the Holder’s designee with DTC for such number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise of this Warrant (as the case may be) (a “Delivery Failure”), then, in addition to all other remedies available to the Holder, (X) the Company shall pay in cash to the Holder on each day after the Share Delivery Date and during such Delivery Failure an amount in cash, as liquidated damages and not as a penalty, equal to 2.0% of the product of (A) the sum of the number of shares of Common Stock not issued to the Holder on or prior to the Share Delivery Date and to which the Holder is entitled, and (B) any trading price of the Common Stock selected by the Holder in writing as in effect at any time during the period beginning on the applicable exercise date and ending on the applicable Share Delivery Date, and (Y) the Holder, upon written notice to the Company, may void its Exercise Notice with respect to, and retain or have returned, as the case may be, any portion of this Warrant that has not been exercised pursuant to such Exercise Notice; provided that the voiding of an Exercise Notice shall not affect the Company’s obligations to make any payments which have accrued prior to the date of such notice pursuant to this Section 1(c) or otherwise. In addition to the foregoing, if on or after such Share Delivery Date the Holder purchases (in an open market transaction or otherwise) shares of Common Stock to deliver in satisfaction of a sale by the Holder of all or any portion of the number of shares of Common Stock issuable upon such exercise that the Holder is entitled to receive from the Company (a “Buy-In”), then, in addition to all other remedies available to the Holder, the Company shall, within three (3) Business Days after the Holder’s request and in the Holder’s discretion, either (i) pay cash to the Holder in an amount equal to the Holder’s total purchase price (including brokerage commissions and other out-of-pocket expenses, if any) for the shares of Common Stock so purchased (including, without limitation, by any other Person in respect, or on behalf, of the Holder) (the “Buy-In Price”), at which point the Company’s obligation to so issue and deliver such certificate (and to issue such shares of Common Stock) or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) (and to issue such Warrant Shares) shall terminate, or (ii) promptly honor its obligation to so issue and deliver to the Holder a certificate or certificates representing such Warrant Shares or credit the balance account of such Holder or such Holder’s designee, as applicable, with DTC for the number of Warrant Shares to which the Holder is entitled upon the Holder’s exercise hereunder (as the case may be) and pay cash to the Holder in an amount equal to the excess (if any) of the Buy-In Price over the product of (A) such number of Warrant Shares multiplied by (B) the Closing Sale Price of the Common Stock on the Share Delivery Date with respect to the related Exercise Notice (the “Buy-In Payment Amount”). The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing shall limit the Holder’s right to pursue any other remedies available to it hereunder, at law or in equity, including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver certificates representing shares of Common Stock (or to electronically deliver such shares of Common Stock) upon the exercise of this Warrant as required pursuant to the terms hereof.

  • No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.

  • CDSCs Related to the Redemption of Non-Omnibus Commission Shares CDSCs in respect of the redemption of Non-Omnibus Commission Shares shall be allocated to the Distributor or a Successor Distributor depending upon whether the related redeemed Commission Share is attributable to the Distributor or such Successor Distributor, as the case may be, in accordance with Part I above.

  • Compensation for Buy-In on Failure to Timely Deliver Certificates Upon Exercise In addition to any other rights available to the Holder, if the Company fails to cause the Transfer Agent to transmit to the Holder a certificate or the certificates representing the Warrant Shares pursuant to an exercise on or before the Warrant Share Delivery Date, and if after such date the Holder is required by its broker to purchase (in an open market transaction or otherwise) or the Holder’s brokerage firm otherwise purchases, shares of Common Stock to deliver in satisfaction of a sale by the Holder of the Warrant Shares which the Holder anticipated receiving upon such exercise (a “Buy-In”), then the Company shall (A) pay in cash to the Holder the amount, if any, by which (x) the Holder’s total purchase price (including brokerage commissions, if any) for the shares of Common Stock so purchased exceeds (y) the amount obtained by multiplying (1) the number of Warrant Shares that the Company was required to deliver to the Holder in connection with the exercise at issue times (2) the price at which the sell order giving rise to such purchase obligation was executed, and (B) at the option of the Holder, either reinstate the portion of the Warrant and equivalent number of Warrant Shares for which such exercise was not honored (in which case such exercise shall be deemed rescinded) or deliver to the Holder the number of shares of Common Stock that would have been issued had the Company timely complied with its exercise and delivery obligations hereunder. For example, if the Holder purchases Common Stock having a total purchase price of $11,000 to cover a Buy-In with respect to an attempted exercise of shares of Common Stock with an aggregate sale price giving rise to such purchase obligation of $10,000, under clause (A) of the immediately preceding sentence the Company shall be required to pay the Holder $1,000. The Holder shall provide the Company written notice indicating the amounts payable to the Holder in respect of the Buy-In and, upon request of the Company, evidence of the amount of such loss. Nothing herein shall limit a Holder’s right to pursue any other remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief with respect to the Company’s failure to timely deliver certificates representing shares of Common Stock upon exercise of the Warrant as required pursuant to the terms hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!