Interim Completion Date definition

Interim Completion Date means the date that Interim Completion has been achieved for any Interim Completion Element.
Sample 1Sample 2
Interim Completion Date means the actual date of achieving Interim Completion as determined pursuant to Section 10.02.
Sample 1Sample 2
Interim Completion Date. The date specified for the completion of ----------------------- Xxxxxxx Xxxxx 0 of a particular Redwood Unit as set forth in Section 2.2 hereof.
Sample 1

Examples of Interim Completion Date in a sentence

  • In the event an Interim Completion Date is not met by the Contractor, the Contractor will submit a written corrective action plan for approval by the Owner which plan will set forth the method by which the next Interim Completion Date will be met.

  • In the event it appears at any such meeting that the Contractor will not meet any Interim Completion Date set forth in the Construction Schedule, the Contractor expressly agrees that it will use its best efforts, including the employment of additional personnel, to see that the Interim Completion Date is met at no additional cost to Owner.

  • Base Progress Payments means all progress payments to be made under GC 5.4 – PROGRESS PAYMENTS for the period from the commencement of the Work to, in the case of the Interim Work, the Interim Completion Date and with respect to the balance of the Work, the Substantial Performance Date in respect to the Guaranteed Price but not including any progress payment in respect to the Additional Owner Payments.

  • The Contractor acknowledges that the Owner needs a minimum of ninety (90) days notice prior to the anticipated Interim Completion Date to prepare for the Commissioning in respect of the Interim Work.

  • The Contractor shall, by the date which is twenty (20) days prior to the anticipated Interim Completion Date as set out in the Contractor’s notice, prepare a list in electronic format on software that identifies deficiencies by division, by trade and by location (the "Interim Preliminary Minor Deficiencies List") of Minor Deficiencies respecting the Interim Work including an estimate of the cost of and the time for rectifying such Minor Deficiencies.

  • Interim Completion Date means the date Completion of the Interim Work is achieved.

  • The Contractor shall plan for start-up and verification of all systems limited to that described for Completion of the Interim Work to be completed no later than seven (7) days prior to the anticipated Interim Completion Date.

  • The Contractor shall reconfirm the anticipated Interim Completion Date in a notice to the Owner and the Consultant by the date which is ten (10) days prior to the anticipated Interim Completion Date.

  • The Contractor shall provide As-Built Drawings and specifications, Record Documents, spare parts and shop drawings in respect of the Interim Work as soon as possible and in any event within thirty (30) days of the Interim Completion Date.

  • Notwithstanding the foregoing, the Contractor shall continue to bear the risk of loss or damage with respect to each phase of the Work until the relevant Phased Occupancy Date in respect of that phase, with respect to the Interim Work until the Interim Completion Date, and with respect to the balance of the Work until the Substantial Performance Date.


More Definitions of Interim Completion Date

Interim Completion Date means a completion date for specified portions of the Contract, so noted because of its importance for co-ordination of the work of more than one contract.
Sample 1

Related to Interim Completion Date

  • Final Completion Date means the date on which Final Completion occurs.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the Completion Date of the Construction as specified in the Statutory Declaration of Completion for the Project;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.

  • Billing Commencement Date means the earlier of:

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Commencement Date means the date of this Agreement;

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.