Performance Targets Threshold, target and maximum performance levels for each performance measure of the performance period are contained in Appendix B.
Goals and Objectives of the Agreement Agreement Goals The goals of this Agreement are to: ● Reduce wildfire risk related to the tree mortality crisis; ● Provide a financial model for funding and scaling proactive forestry management and wildfire remediation; ● Produce renewable bioenergy to spur uptake of tariffs in support of Senate Bill 1122 Bio Market Agreement Tariff (BioMat) for renewable bioenergy projects, and to meet California’s other statutory energy goals; ● Create clean energy jobs throughout the state; ● Reduce energy costs by generating cheap net-metered energy; ● Accelerate the deployment of distributed biomass gasification in California; and ● Mitigate climate change through the avoidance of conventional energy generation and the sequestration of fixed carbon from biomass waste. Ratepayer Benefits:2 This Agreement will result in the ratepayer benefits of greater electricity reliability, lower costs, and increased safety by creating a strong market demand for forestry biomass waste and generating cheap energy. This demand will increase safety by creating an economic driver to support forest thinning, thus reducing the risk of catastrophic wildfire and the associated damage to investor-owned utility (IOU) infrastructure, such as transmission lines and remote substations. Preventing this damage to or destruction of ratepayer-supported infrastructure lowers costs for ratepayers. Additionally, the ability of IOUs to use a higher- capacity Powertainer provides a much larger offset against the yearly billion-dollar vegetation management costs borne by IOUs (and hence by ratepayers). The PT+’s significant increase in waste processing capacity also significantly speeds up and improves the economics of wildfire risk reduction, magnifying the benefits listed above. The PT+ will directly increase PG&E’s grid reliability by reducing peak loading by up to 250 kilowatt (kW), and has the potential to increase grid reliability significantly when deployed at scale. The technology will provide on-demand, non- weather dependent, renewable energy. The uniquely flexible nature of this energy will offer grid managers new tools to enhance grid stability and reliability. The technology can be used to provide local capacity in hard-to-serve areas, while reducing peak demand. Technological Advancement and Breakthroughs:3 This Agreement will lead to technological advancement and breakthroughs to overcome barriers to the achievement of California’s statutory energy goals by substantially reducing the LCOE of distributed gasification, helping drive uptake of the undersubscribed BioMAT program and increasing the potential for mass commercial deployment of distributed biomass gasification technology, particularly through net energy metering. This breakthrough will help California achieve its goal of developing bioenergy markets (Bioenergy Action Plan 2012) and fulfil its ambitious renewable portfolio standard (SB X1-2, 2011-2012; SB350, 2015). The PT+ will also help overcome barriers to achieving California’s greenhouse gas (GHG) emissions reduction (AB 32, 2006) and air quality improvement goals. It reduces greenhouse gas and criteria pollutants over three primary pathways: 1) The PT+’s increased capacity and Combined Heat and Power (CHP) module expand the displacement of emissions from conventional generation; 2) the biochar offtake enables the sequestration of hundreds of tons carbon that would otherwise have been released into the atmosphere; and 3) its increased processing capacity avoids GHG and criteria emissions by reducing the risk of GHG emissions from wildfire and other forms of disposal, such as open pile burning or decomposition. The carbon sequestration potential of the biochar offtake is particularly groundbreaking because very few technologies exist that can essentially sequester atmospheric carbon, which is what the PT+ enables when paired with the natural forest ecosystem––an innovative and groundbreaking bio-energy technology, with carbon capture and storage. Additionally, as noted in the Governor’s Clean Energy Jobs Plan (2011), clean energy jobs are a critical component of 2 California Public Resources Code, Section 25711.5(a) requires projects funded by the Electric Program Investment Charge (EPIC) to result in ratepayer benefits. The California Public Utilities Commission, which established the EPIC in 2011, defines ratepayer benefits as greater reliability, lower costs, and increased safety (See CPUC “Phase 2” Decision 00-00-000 at page 19, May 24, 2012, xxxx://xxxx.xxxx.xx.xxx/PublishedDocs/WORD_PDF/FINAL_DECISION/167664.PDF). 3 California Public Resources Code, Section 25711.5(a) also requires EPIC-funded projects to lead to technological advancement and breakthroughs to overcome barriers that prevent the achievement of the state’s statutory and energy goals. California’s energy goals. When deployed at scale, the PT+ will result in the creation of thousands of jobs across multiple sectors, including manufacturing, feedstock supply chain (harvesting, processing, and transportation), equipment operation, construction, and project development. ● Annual electricity and thermal savings; ● Expansion of forestry waste markets; ● Expansion/development of an agricultural biochar market; ● Peak load reduction; ● Flexible generation; ● Energy cost reductions; ● Reduced wildfire risk; ● Local air quality benefits; ● Water use reductions (through energy savings); and ● Watershed benefits.
Targets and Milestones You may choose to develop specific additional targets and milestones which assess your performance in ITT over time – particularly if ITT trainees make up a significant proportion of your overall student body. Alternatively, you may have targets and milestones in your existing 2012-13 access agreement which you now also wish to apply to undergraduate and/or postgraduate ITT trainees. These targets may be statistical – based on how representative your entrants are and/or your retention performance – and might include annual or interim milestones to help you monitor whether you are making progress. You may wish to include criteria around the numbers of trainees in receipt of a full or partial maintenance grant, as financial data will need to be collected to determine bursary support and the data will also be accessible through the Student Loans Company for HEBSS subscribers. You may also wish to consider the TDA guidance at Annex C which gives information on specific groups that are underrepresented in the teaching profession.
Milestones Subject to the provisions of the SGIP, the Parties shall agree on milestones for which each Party is responsible and list them in Attachment 4 of this Agreement. A Party’s obligations under this provision may be extended by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately notify the other Parties of the reason(s) for not meeting the milestone and (1) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (2) requesting appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not unreasonably withhold agreement to such an amendment unless it will suffer significant uncompensated economic or operational harm from the delay, (1) attainment of the same milestone has previously been delayed, or (2) it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.
Performance; No Default The Company shall have performed and complied with all agreements and conditions contained in this Agreement required to be performed or complied with by it prior to or at the Closing. Before and after giving effect to the issue and sale of the Notes (and the application of the proceeds thereof as contemplated by Section 5.14), no Default or Event of Default shall have occurred and be continuing.
Targets Seller’s supplier diversity spending target for Work supporting the construction of the Project prior to the Commercial Operation Date is ____ percent (___%) as measured relative to Seller’s total expenditures on construction of the Project prior to the Commercial Operation Date, and;
MANAGEMENT OF EVALUATION OUTCOMES 12.1 Where the Employer is, any time during the Employee’s employment, not satisfied with the Employee’s performance with respect to any matter dealt with in this Agreement, the Employer will give notice to the Employee to attend a meeting;
12.2 The Employee will have the opportunity at the meeting to satisfy the Employer of the measures being taken to ensure that his performance becomes satisfactory and any programme, including any dates, for implementing these measures;
12.3 Where there is a dispute or difference as to the performance of the Employee under this Agreement, the Parties will confer with a view to resolving the dispute or difference; and
12.4 In the case of unacceptable performance, the Employer shall –
12.4.1 Provide systematic remedial or developmental support to assist the Employee to improve his performance; and
12.4.2 After appropriate performance counselling and having provided the necessary guidance and/or support as well as reasonable time for improvement in performance, the Employer may consider steps to terminate the contract of employment of the Employee on grounds of unfitness or incapacity to carry out his or her duties.
Development Milestone Payments (i) In addition to the Closing Date Merger Consideration (less the Remaining Option Consideration and Rights Proceeds Amount, if any) and any Net TNF Sales Payments (as defined below), upon the attainment of the development ** Portions of the Exhibit have been omitted and have been filed separately pursuant to an application for confidential treatment filed with the Securities and Exchange Commission pursuant to Rule 24b-2 under the Securities Exchange Act of 1934, as amended. milestones set forth below (each, a “Development Milestone”), Parent shall, or shall cause the Surviving Corporation to, [**] after the occurrence of each Development Milestone, deliver to the Paying Agent (for further payment to the holders of Stock Certificates and Stock Agreements outstanding immediately prior to the Effective Time), via wire transfer of immediately available funds, the respective amounts set forth below minus, in each case, the applicable Contingent Consideration Distribution Fee associated therewith and any amount designated by the Stockholders’ Representatives to be placed in the Administrative Expense Account (each, a “Development Milestone Payment” and collectively, the “Development Milestone Payments”):
(A) Upon FDA approval of Reslizumab for the treatment of eosinophilic esophagitis, a cash payment of [**];
(B) Upon marketing authorization of Reslizumab for the treatment of eosinophilic esophagitis being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**];
(C) If Res 5-0010 Asthma Study Completion has not occurred on or prior to the Closing Date, then upon the occurrence of the Res 5-0010 Asthma Study Completion, a cash payment of $50,000,000 (fifty million dollars) (the “Res 5-0010 Asthma Payment”);
(D) Upon FDA approval of Reslizumab for any asthma indication, a cash payment of [**];
(E) Upon marketing authorization of Reslizumab for the treatment of any asthma indication being granted by the European Commission in accordance with Regulation (EC) No. 726/2004, a cash payment of [**]; and
(F) Upon FDA approval of an Oral Anti-TNF Product, a cash payment of [**].
Milestone A principal event specified in the Contract Documents including the Material Completion and Occupancy Date and other events relating to an intermediate completion date or time.
Placement of EPP probes Probes for measuring EPP parameters shall be placed inside or close to Registrars points of access to the Internet across the different geographic regions; care shall be taken not to deploy probes behind high propagation-‐delay links, such as satellite links.
