SERVICE REQUIREMENTS 7. REQUISITOS DE SERVICIO Sample Clauses

SERVICE REQUIREMENTS 7. REQUISITOS DE SERVICIO. If the Purchase Contract applies to materials or components, Seller agrees to supply Buyer Products and/or related Services for a period of fifteen (15) years after the end of any mass production program in which Seller’s Products or Services are being incorporated, at the same Price in effect at the end of the mass production program plus actual costs incurred for special packaging and shipping for the first five (5) years, and subsequently at a mutually-agreed Price taking into account actual, documented differences in the cost of materials, packaging, and costs of production. Si el Contrato de Compra se aplica a materiales o componentes, el Vendedor acuerda suministrar Productos del Comprador y/o Servicios relacionados durante un período de quince (15) años después de la terminación de cualquier programa de producción en serie en el que xx xxxxx incorporando los Productos o Servicios del Vendedor, al mismo Precio vigente al final del programa de producción en serie más los costos reales incurridos por el empaque especial y el envío durante los primeros cinco (5) años, y posteriormente a un Precio mutuamente acordado que tenga en cuenta las diferencias reales y documentadas en el costo de los materiales, el empaque y los costos de producción.
Sample 1
AutoNDA by SimpleDocs

Related to SERVICE REQUIREMENTS 7. REQUISITOS DE SERVICIO

  • Compliance with Xxxxx-Xxxxx and Related Act requirements All rulings and interpretations of the Xxxxx-Xxxxx and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein incorporated by reference in this contract.

  • Compliance with Xxxxxxxx Act requirements The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.

  • Federal Medicaid System Security Requirements Compliance Party shall provide a security plan, risk assessment, and security controls review document within three months of the start date of this Agreement (and update it annually thereafter) in order to support audit compliance with 45 CFR 95.621 subpart F, ADP System Security Requirements and Review Process.

  • W-9 Requirement Alongside a signed copy of this Agreement, Grantee will provide Florida Housing with a properly completed Internal Revenue Service (“IRS”) Form W-9. The purpose of the W-9 form is to document the SS# or FEIN# per the IRS. Note: W-9s submitted for any other entity name other than the Grantee’s will not be accepted.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Additional Service Requirements Grantee shall:

  • Meteorological Data Reporting Requirement (Applicable to wind generation facilities only) The wind generation facility shall, at a minimum, be required to provide the Transmission Provider with site-specific meteorological data including: • Temperature (degrees Fahrenheit) • Wind speed (meters/second) • Wind direction (degrees from True North) • Atmosphere pressure (hectopascals) • Forced outage data (wind turbine and MW unavailability)

  • Child Abuse Reporting Requirement Grantee will:

Time is Money Join Law Insider Premium to draft better contracts faster.