Risk of Loss; Insurance A. Landlord and Tenant shall each be responsible for loss, damage, or injury caused by its own negligence or willful conduct.
Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver. Unless otherwise required by a contract of Buyer with a customer of Buyer with respect only to products ordered by such customer, Title shall not pass with respect to any products ordered until Buyer makes payment in full thereof. In the alternative, Seller reserves a purchase money security interest in the products sold as well as any other products or property forwarded to Seller by Buyer for servicing or evaluation until full payment has been received. Buyer agrees to execute any document appropriate or necessary to perfect Seller's security interest or to acknowledge that title remains with Seller. In the alternative, Seller may file this order as a financing statement and/or chattel mortgage. Buyer agrees that, upon its failure to pay any invoice when due, Seller may immediately foreclose upon and sell, in a manner determined by Seller, any products or property owned by or provided by Buyer to Seller, regardless of whether such products or property are the subject of the unpaid invoice, in order to allow Seller to recover all amounts, including but not limited to interest and penalties, owed by Buyer to Seller.
LIABILITY AND RISK OF LOSS A. Each Party hereby waives any claim against the other Party, employees of the other Party, the other Party's Related Entities (including but not limited to contractors and subcontractors at any tier, grantees, investigators, customers, users, and their contractors or subcontractor at any tier), or employees of the other Party's Related Entities for any injury to, or death of, the waiving Party's employees or the employees of its Related Entities, or for damage to, or loss of, the waiving Party's property or the property of its Related Entities arising from or related to activities conducted under this Agreement, whether such injury, death, damage, or loss arises through negligence or otherwise, except in the case of willful misconduct.
Title and Risk of Loss Notwithstanding the form of shipment, title or other property interest, risk of loss shall not pass from the Contractor to the Authorized User until the Products have been received, inspected and accepted by the receiving entity. Acceptance shall occur within a reasonable time or in accordance with such other defined acceptance period as may be specified in the Bid Specifications or Purchase Order. Mere acknowledgment by Authorized User personnel of the delivery or receipt of goods (e.g., signed xxxx of lading) shall not be deemed or construed as acceptance of the Products received. Any delivery of Product that is substandard or does not comply with the Bid Specifications or Contract terms and conditions, may be rejected or accepted on an adjusted price basis, as determined by the Commissioner.
DELIVERY - RISK OF LOSS Deliveries must be made both in quantities and at times specified on the face of the Purchase Order or in Buyer's schedules and time is of the essence. Buyer’s delivery schedules are an integral part of the Purchase Order, are governed by these terms and conditions and are not independent contracts. ▪ Buyer will not be required to make payment for goods delivered to Buyer that are in excess of quantities specified in Buyer's delivery schedule on the Purchase Order or in written releases issued by Buyer. Buyer may reject any deliveries made after or before the specified delivery date. Seller will bear all costs and damages incurred by Buyer due to late or early delivery. ▪ If Seller fails to meet the agreed upon delivery requirements for reasons other than those specified in paragraph 13 below, and Buyer requires a more expeditious method of transportation for the goods than the transportation method originally specified, Seller shall ship the goods as expeditiously as possible at Seller's expense and invoice Buyer for the amount, if any, that Buyer would have paid for normal shipment. ▪ Unless provided otherwise in the Purchase Order, all goods are sold DAP. Seller shall be responsible for and bear the risk of any loss or damage to the goods until received by the Buyer.
DELIVERY, TITLE AND RISK OF LOSS Unless otherwise specified on the EDDYFI quotation, delivery is FCA (Manufacturing Site). In any case, delivery and risk of loss is in accordance with INCOTERMS 2010. Title to products shall pass to the Customer upon full payment of the invoice(s). In the absence of specific instructions, goods will be shipped via the carrier EDDYFI deems most practical. No claim for error in shipment will be considered unless made within ten (10) days of Customer’s receipt of goods.
Risk of Loss and Insurance The State shall not be liable to Contractor for any risk of Deliverable loss or damage while Deliverables are in transit, or while in the Client Agency’s possession, except when such loss or damage is due directly to the Client Agency’s negligence or intentional misconduct. Nothing in this Section is intended nor shall it be construed, in any manner, as waiving or compromising the sovereign immunity of the State. The insurance required by this Section shall be written on an occurrence basis as opposed to a “claims made” basis and shall be on such forms, and contain such endorsements and terms, as shall be acceptable to DAS. Before commencing Performance, the Contractor shall obtain and maintain at its own cost and expense for the Term of this Contract, the insurance described below. Contractor shall assume any and all deductibles in the described insurance policies. The Contractor’s insurers shall have no right of recovery or subrogation against the State and the described Contractor’s insurance shall be primary coverage. Any failure to comply with the claim reporting provisions of the policy shall not affect coverage provided to the State.
Mitigation of costs and damage The Affected Party shall make all reasonable efforts to mitigate or limit the costs and damage arising out of or as a result of breach of Agreement by the other Party.
Risk of Loss Matters of inspection and acceptance are addressed in section 215.422, F.S. Until acceptance, risk of loss or damage will remain with the Contractor. The Contractor will be responsible for filing, processing, and collecting all damage claims. To assist the Contractor with damage claims, the Customer will: record any evidence of visible damage on all copies of the delivering xxxxxxx’x xxxx of lading; report damages to the carrier and the Contractor; and provide the Contractor with a copy of the xxxxxxx’x xxxx of lading and damage inspection report.
RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.
