Special Requirements for Goods
Special Requirements for Goods Sample Clauses
Related to Special Requirements for Goods
Additional Requirements for All Policies All policies shall be endorsed to provide at least thirty (30) days' advance written notice to City of cancellation of policy for any reason, nonrenewal or reduction in coverage and specific notice mailed to City's address for notices pursuant to Article 15.
Special Requirements Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the “Special Requirements” attached hereto as Exhibit “B” and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit “B” and any other provisions of this Agreement, the provisions of Exhibit “B” shall govern.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Financial Requirements A report of monthly and cumulative financial requirements; and
Requirements for All Policies Each policy of insurance required under this Section 11.1 shall: (i) be in a form, and written by an insurer, reasonably acceptable to Landlord, (ii) be maintained at Tenant’s sole cost and expense, and (iii) require at least thirty (30) days’ written notice to Landlord prior to any cancellation, nonrenewal or modification of insurance coverage. Insurance companies issuing such policies shall have rating classifications of “A” or better and financial size category ratings of “VII” or better according to the latest edition of the A.M.
General Requirements The Contractor hereby agrees:
Personnel Requirements a. The CONTRACTOR shall secure, at the CONTRACTOR'S own expense, all personnel required to perform this Contract.
Certain State Law Requirements for Contracts The contents of this Section are required by Texas Law and are included by County regardless of content.
