Specified task or project refers to a definable task that has a start date and an anticipated finish date.
Specified task or project Sample Clauses
Related to Specified task or project
Credit for Project Work In order to compensate PURCHASER for project work that PURCHASER agrees to complete under the section titled, “Project Work,” of this contract, STATE agrees to credit PURCHASER’s timber account in the sum of $46,657 upon completion of and STATE’s acceptance of all work, unless otherwise approved in writing by STATE. PURCHASER may request partial credit for project work when PURCHASER has completed and STATE has accepted project work, in accordance with the following credit schedule: Partial credit amount of $24,999 (Project No. 1 completion) Partial credit amount of $ 545 (Project No. 2 completion) Partial credit amount of $ 2,721 (Project No. 3 completion) Partial credit amount of $ 1,753 (Project No. 4 completion) Partial credit amount of $16,639 (Project No. 5 completion)
Volume or Maintenance License If you obtained the Apple Software under a volume or maintenance license program with Apple, the terms of your volume or maintenance license will determine the number of copies of the Apple Software you are permitted to download, install, use and run on Apple-branded computers you own or control. Except as agreed to in writing by Apple, all other terms and conditions of this License shall apply to your use of the Apple Software obtained under a volume or maintenance license.
000 APPLICATION FOR PROJECT AGREEMENT 1.100 Any Company desiring to enter into a Project Agreement for Maintenance by Contract, must appear before the General Presidents' Committee (hereinafter the "Committee") for purposes of review and orientation and present to the Committee written evidence of the Owner's intent to engage that Company in the performance of maintenance service for a minimum period of one full year, subject to the usual termination clauses in such contracts.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Four Day Work Week Schedule i. When working under the four (4) day work week schedule, Employees shall be paid at double time (2x) the regular hourly rate for all hours worked in excess of the regular ten (10) hours per day Monday through Thursday.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
MAINTENANCE OF THE BUILDING /APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the Association upon the issuance of the completion certificate of the Project. The cost of such maintenance has been included in the Total Extras and Deposits as mentioned in clause 1.2.
Requirement for Project Planning No physical work will begin on the construction site until the receipt of a Proceed Order issued by the Owner. The Contract assumes that a Proceed Order will be issued in not more than sixty days from the Effective Date of the Contract. Failure of the Contractor to provide the necessary documentation for the issuance of a Proceed Order shall not entitle the Contractor to any extension of time. If a Proceed Order is not issued within sixty days from the award of the Contract and non-issuance is due to nonperformance by the Contractor, the Contractor may be in default.
MAINTENANCE OF CONCESSION PREMISES A. Concessionaire shall preserve and maintain the Concession Premises in good and clean condition, reasonable wear and tear excepted. Concessionaire is solely responsible for the maintenance and cleanliness of the Concession Premises.
Sunday Work Employees required to work overtime on Sundays shall be paid for a minimum of three hours work at double time. The double time is to be paid until the employee is relieved from duty.
