Stadium and Non Stadium Alternatives
Stadium and Non Stadium Alternatives Sample Clauses
Related to Stadium and Non Stadium Alternatives
Capital Improvements From and after Final Completion, Tenant shall not replace or materially alter the Project, or any part thereof (except as provided to the contrary with respect to Fixtures in Article 13), or make any addition thereto, whether voluntarily or in connection with repairs required by this Lease (collectively, “Capital Improvements”), unless Tenant shall comply with the following requirements and, if applicable, with the additional requirements set forth in Section 11.10: (a) No Capital Improvements shall be undertaken, as applicable, until Tenant shall have procured from all Governmental Authorities and paid for all permits, consents, certificates and approvals for the proposed Capital Improvements which are required to be obtained prior to the commencement of the proposed Capital Improvements (collectively, “Improvement Approvals”). The FCRHA shall not unreasonably refuse to join or otherwise unreasonably refuse to cooperate in the application for any such Improvement Approvals, provided such application is made without cost, expense or liability (contingent or otherwise) to the FCRHA. True copies of all such Improvement Approvals shall be delivered by Tenant to the FCRHA prior to commencement of the proposed Capital Improvements. (b) The Premises after completion of such Capital Improvements, shall have a value at least equal to the value of the Premises immediately before construction of such Capital Improvements. In addition, the Project shall at all times remain in substantial conformity with the original Plans and Specifications therefor (except to the extent specifically consented to by the FCRHA, in its sole but reasonable discretion). (c) All Capital Improvements shall be made with reasonable diligence and continuity (subject to Unavoidable Delays) and in a good and workmanlike manner and in compliance with (i) all Improvement Approvals, (ii) if required pursuant to Section 11.10(a) or (b), in substantial accordance with the plans and specifications for such Capital Improvements as approved by the FCRHA, and (iii) all Applicable Laws. (d) No construction of any Capital Improvement shall be commenced until Tenant shall have delivered to the FCRHA certificates of insurance and copies of the declaration page(s) for the insurance required by Exhibit D. Such insurance policies shall comply with the terms of Section 7.02 above.
Initial Improvements Subtenant may, at its option and subject to the provisions of the Prime Lease, including, without limitation, Article 8 thereof, complete certain initial improvements to prepare the Demised Premises for Subtenant’s occupancy thereof as described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B (the “Initial Improvements”), at Subtenant’s sole cost and expense without any contribution or improvement allowance from Sublandlord described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B); provided, however, Subtenant shall not make or permit anyone to make any Initial Improvements without the prior written consent of Sublandlord, which shall not be unreasonably withheld or delayed, and of Prime Landlord in accordance with the Prime Lease. In connection with the foregoing, Subtenant shall submit to Sublandlord, for prior written approval by Sublandlord, which shall not be unreasonably withheld or delayed, and Prime Landlord, complete plans and specifications for any and all Initial Improvements; including, without limitation, schematic designs and work drawings. Any and all costs and expenses associated with the acquisition of cabling, equipment, furniture, security systems, or other personal property for Subtenant or the Demised Premises or the installation or placement of any of the foregoing within the Demised Premises or with the project management for the performance of the Initial Improvements (collectively, “Subtenant’s Personal Property and Services”), shall be paid for by and be the sole responsibility of Subtenant. Sublandlord acknowledges and agrees that Subtenant shall not be required to remove any Initial Improvements upon the expiration or earlier termination of this Sublease unless the removal is required by Prime Landlord or Sublandlord is otherwise obligated to pay Prime Landlord the costs of any removal of any Initial Improvements pursuant to Section 8(e) of the Prime Lease.
Communications Equipment (a) Subject to the provisions of this Section 3.5, Tenant shall have the non-exclusive right, at its sole cost and expense and for Tenant’s use, to install, maintain and operate upon the roof of the Building one (1) or a reasonable and necessary additional number of transmitters and/or receiver antennas or dishes approved by Landlord, which approval shall not be unreasonably withheld or delayed (collectively, the “Communications Equipment”) for use by Tenant in the conduct of its business; provided that such Communications Equipment may not materially compromise the aesthetics or appearance of the Building nor shall Landlord be required to incur any expense in accommodating the Communications Equipment. The Communications Equipment must be (i) designed, installed and operated in compliance with all Legal Requirements, and (ii) installed and operated so as not to adversely affect or impact structural, mechanical, electrical, elevator, or other systems serving the Building or customary telephone service for the Building and so as not to cause injury to persons or property, and without limitation of the foregoing, so as not to void or impair any applicable roof warranty. Upon the expiration or termination of this Lease, Tenant shall remove the Communications Equipment and repair any damage to the Building caused by the installation, maintenance, use or removal of the Communications Equipment. (b) Landlord hereby grants to Tenant the right to install (at Tenant’s sole cost and expense) any additional equipment required to operate the Communications Equipment and to connect the Communications Equipment to Tenant’s other machinery and equipment located in the Leased Premises (e.g., conduits and cables) in the shafts, ducts, chases and utility closets located in the core of the building (“Additional Equipment”), which Additional Equipment shall be deemed a part of the Communications Equipment for all purposes of this Section 3.5; provided that (i) the use of such space in the Building core by Tenant (except customary chases for cabling) may not materially adversely affect the marketability of the remaining space on any floor of the Building, and (ii) to the extent any such Additional Equipment occupies space (other than space in customary chases for the Building) that would have otherwise been Net Rentable Area on a floor of the Building, such space shall be included within the Net Rentable Area of the Leased Premises and Tenant shall be obligated to pay Annual Basic Rent and Additional Rent with respect to such space as if such space was included in the Leased Premises. Tenant’s use of such space in the Building core shall be subject to the provisions of this Lease relating to Tenant’s use of Common Areas of the Building. (c) Subject to the Building Rules and other reasonable rules relating to Building security and safety that may be promulgated by Landlord pertaining to access by tenants to the roof of the Building and provided Tenant does not unreasonably disturb any other tenants of the Building, Tenant and Tenant’s contractors shall have reasonable access to the Communications Equipment and the Additional Equipment for purposes of operating, servicing, repairing or otherwise maintaining said equipment. (d) Nothing contained in this Section 3.5 shall be deemed to prohibit or restrict any other individual or entity, including Landlord or any other tenant of the Building, from installing communications equipment on the roof of the Building or to use the roof for any other purpose. (e) In connection with its installation, repair, maintenance and removal of any Communications Equipment and Additional Equipment, Tenant, at Tenant’s sole cost and expense, shall comply with all applicable Building Rules and Legal Requirements and repair any damage to the Building caused by such installation, repair, maintenance or removal. In the event that the placement of Tenant’s Communications Equipment or Additional Equipment interferes with Landlord’s performance of any repair or maintenance to the Common Areas, including the roofs of the Buildings, any costs incurred by Landlord to temporarily or permanently relocate and reinstall Tenant’s Communications Equipment or Additional Equipment shall be included in the cost of such repair or maintenance as a Operating Expense. (f) Tenant’s Communications Equipment and Additional Equipment existing as of the Commencement Date are hereby deemed to be approved by Landlord. Any changes to the existing Communications Equipment and/or Additional Equipment by Tenant shall first be approved by Landlord, which approval will not be unreasonably withheld or delayed. (g) If Landlord shall place on the roof of any Building communications equipment of its own, or shall grant to any third party the right to locate and maintain any such equipment, all such equipment shall be located, designed and operated so as not to interfere with signals to and from Tenant’s Communications Equipment and Additional Equipment, the installation of which, in accordance with this Section 3.5, predates the installation of such other equipment. Similarly, any Communications Equipment and Additional Equipment hereafter installed by Tenant shall be located and designed so as not to interfere with signals to and from such other equipment belonging to Landlord or to third parties, that may have previously been installed. The party responsible for the communications equipment which interferes with equipment previously installed by others shall be required, at its or their expense, to take all measures necessary to eliminate the source of interference caused by such party’s equipment.
Common Facilities “Common Facilities” includes all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Property, and their employees, agents, customers and other invitees, including without limitation building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Property, comfort and first-aid stations, parcel pick-up stations and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord shall have the right, without liability to Tenant, to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time, and Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to enforce parking charges (by operation of meters or otherwise), with appropriate provisions for free parking ticket validating by tenants; to close all or any portion of the Common Facilities to such extent as may, in the opinion of Landlord’s counsel, be legally sufficient to prevent a dedication thereof or the accrual of any rights to any person or the public therein; to close temporarily all or any portion of the Common Facilities; to discourage non-customer parking; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, Tenant may use all Common Facilities not within the Premises, under a revocable license, on a nonexclusive basis in common with other tenants. If any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.
Alterations to Premises Tenant shall make no structural or interior alterations to the Premises. If Tenant requests such alterations and such alterations are structural in nature, then Tenant shall provide Landlord with a complete set of construction drawings. If Landlord consents to the alterations, then the Landlord shall determine the actual cost of the work to be done. Tenant may then either agree to pay Landlord to have the work done or withdraw its request for alterations; provided, however, that at Tenant’s request, Landlord shall not unreasonably withhold its consent to allowing Tenant and/or Tenant’s contractors to perform such work. All such alterations are subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to the terms of this paragraph, and notwithstanding any provision of this Lease to the contrary, Landlord agrees to allow Tenant to construct (i) a data center within the Premises and to install equipment (which may include generator, condensers, UPS, etc.) in the Building and around the land surrounding the Building necessary to facilitate the operation of Tenant’s data center, and (ii) an opening in the curtain wall of Floor 1 of Building C, to install two (2) four foot doors within such opening, to improve the outside area for delivery access and to install other improvements (which may include a large dumpster) to the Building and the land surrounding the Building necessary to facilitate the operation of Tenant’s Fulfillment Center. All such alterations shall be performed by Tenant’s contractors (which shall be subject to Landlord’s approval, not to be unreasonably withheld), at Tenant’s sole cost and expense. Notwithstanding the above paragraph, Tenant shall have the right to make nonstructural and nonsystems related alterations (“Tenant Alterations”) up to a value of $15,000.00 per occurrence (not to exceed $60,000 during any 12-month period) without Landlord’s prior written consent (which consent shall not be unreasonably withheld), provided Tenant shall provide notice to Landlord of its intent to make the Tenant Alterations. Such notice shall include a copy of plans and specifications (if such alterations are of a character that would reasonably require plans and specifications) and copies of all permits, if required by the appropriate municipality, and any contracts for such Tenant Alterations. All Tenant Alterations shall be performed by contractors approved by Landlord which approval shall not be unreasonably withheld, and in accordance with all applicable laws and the rules and regulations described in Section 12b.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
ROADWAY DESIGN MISCELLANEOUS (ROADWAY)
