Labeling Upon request, Lessee will xxxx the Equipment indicating Lessor's interest with labels provided by Lessor. Lessee will keep all Equipment free from any other marking or labeling which might be interpreted as a claim of ownership.
Materials of Environmental Concern have not been transported or disposed of from the Properties in violation of, or in a manner or to a location that could give rise to liability under, any Environmental Law, nor have any Materials of Environmental Concern been generated, treated, stored or disposed of at, on or under any of the Properties in violation of, or in a manner that could give rise to liability under, any applicable Environmental Law;
STORAGE TANKS AND SUMPS 3.1 Is any above or below ground storage of gasoline, diesel, petroleum, or other Hazardous Materials in tanks or sumps proposed in, on or about the Premises? Existing Tenants should describe any such actual or proposed activities. Yes [ ] No [ ] If yes, please explain:
Materials of Environmental Concern “Materials of Environmental Concern” include chemicals, pollutants, contaminants, wastes, toxic substances, petroleum and petroleum products and any other substance that is now or hereafter regulated by any Environmental Law or that is otherwise a danger to health, reproduction or the environment.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Waste Borrower shall not commit or suffer any waste of the Property or make any change in the use of the Property which will in any way materially increase the risk of fire or other hazard arising out of the operation of the Property, or take any action that might invalidate or give cause for cancellation of any Policy, or do or permit to be done thereon anything that may in any way impair the value of the Property or the security of this Security Instrument. Borrower will not, without the prior written consent of Lender, permit any drilling or exploration for or extraction, removal, or production of any minerals from the surface or the subsurface of the Land, regardless of the depth thereof or the method of mining or extraction thereof.
Storage Tanks If storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks. Notwithstanding anything to the contrary contained herein, Tenant shall have no right to use or install any underground storage tanks at the Project.
Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.
Supply of Materials Unless the parties otherwise agree in a Work Order, Manufacturer will supply, in accordance with the relevant approved raw material specifications, all materials to be used by Manufacturer in the performance of Services under a Work Order other than the Rhythm Materials specified in such Work Order. Rhythm or its designees will provide Manufacturer with the Rhythm Materials. Manufacturer agrees (a) to account for all Rhythm Materials, (b) not to provide Rhythm Materials to any third party (other than an Affiliate acting as a permitted subcontractor) without the express prior written consent of Rhythm, (c) not to use Rhythm Materials for any purpose other than conducting the Services, including, without limitation, not to analyze, characterize, modify or reverse engineer any Rhythm Materials or take any action to determine the structure or composition of any Rhythm Materials unless required * CONFIDENTIAL TREATMENT REQUESTED. OMITTED PORTIONS FILED WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 PROMULGATED UNDER THE SECURITIES ACT OF 1933, AS AMENDED. pursuant to a signed Work Order, and (d) to destroy or return to Rhythm all unused quantities of Rhythm Materials according to Rhythm’s written directions.
Storage Any storage space at any time leased to Tenant hereunder shall be used exclusively for storage. Notwithstanding any other provision of this Lease to the contrary, (i) Landlord shall have no obligation to provide heating, cleaning, water or air conditioning therefor, and (ii) Landlord shall be obligated to provide to such storage space only such electricity as will, in Landlord’s judgment, be adequate to light said space as storage space.
